Legals & Public Notices: May 15, 2026

City of Sioux Falls, Sioux Falls School District, City of Baltic, Sheriff's Sales, Foreclosure Sales, Name Changes, Notices to Creditors, Summons

May 15, 2026

CITY OF SIOUX FALLS

PUBLISH: May 15 & May 22, 2026

BID REQUEST NO. 26-1002
NOTICE TO BIDDERS

The City of Sioux Falls, SD requests formal bids for: Sherman Park Shop Building.

To participate, you must be registered as a vendor on the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, June 4, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at https://www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the e-procurement poral for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make Award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on May 15 & May 22, 2026, at the approximate cost of $31.90, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15 & May 22, 2026

BID REQUEST NO. 26-1077
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for Southeast Basins Sanitary Sewer Improvements - Phase 1.

Bids will be electronically submitted through the e-procurement portal and will be received by the e-procurement portal not later than 2 p.m., June 4, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

It is the bidder’s responsibility to check the e-procurement portal for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the e-procurement portal.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Federal financial assistance will be used to fund all or a portion of the contract. The contractor will comply with all applicable federal laws, regulations, executive orders, federal policies, procedures, and directives including, but not limited to 2 CFR

§§200.318-200.327.

The City of Sioux Falls has adopted a Disadvantaged Business Enterprise Plan. This plan expresses the commitment of the City of Sioux Falls that disadvantaged business enterprises have the maximum opportunity to compete for and perform federally assisted contracts and subcontracts.

The City of Sioux Falls Program Administrator will be available to assist in the facilitation of identifying those certified disadvantaged business enterprises, if any, within the state of South Dakota.

Bidders for this work will be required to comply with the President’s Executive Order No(s). 14173, 11518 and 11625 as amended. The requirements for bidders and contractors under these orders are explained in the specifications.

Bidders on this work will be required to comply with Title 40 CFR 33 and Executive Order 12138. The requirements for bidders and contractors under this regulation, which concerns utilization of Disadvantaged Business Enterprises (DBE), are explained in the specifications. The DBE goals for participation in this contract in terms of percentage of contract value are as follows: MBE 1.5 percent; WBE 2.4 percent.

Only firms certified at the time of the letting and included on the DBE Directory, will count toward DBE participation.

Davis-Bacon and Related Acts wages apply to this project. All provisions relating to those Acts must be met.

All bidders must be registered in the System for Award Management (SAM.gov), provide their Unique Entity Identifier (UEI), and have an active status.

Bidders must also certify that they are in compliance with all federal requirements applicable to the assistance received (including those imposed by the Infrastructure Investment and Jobs Act (“IIJA”), Public Law No. 117-58, which the bidder understands includes, but is not limited to, the following requirements: that all of the iron and steel, manufactured products, and construction materials used in the project are to be produced in the United States (“Build America, Buy America Requirements”). Bidders must also comply with all record-keeping and reporting requirements under all applicable legal authorities, including any reports required by the funding authority (such as EPA and/or a state), such as performance indicators for program deliverables, cost information, and project progress.

Please be advised that waivers or exemptions from the Build America, Buy America Act provision that cites International Trade Agreements DO NOT comply with the Build America, Buy America Act as it applies to the SRF programs. Claims from suppliers that the Build America, Buy America Act provision do not apply to certain products based on the International Trade Agreement exemptions of the Build America, Buy America Act (Public Law No. 117-58) will not be accepted.

The low responsive bidder must assure compliance with the requirements of Public Law 115-232, Section 889, Prohibition on Certain Telecommunications and Video Surveillance Services or Equipment. Contractors must assure that telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities), and video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities) WILL NOT be supplied for the project.

Your special attention is invited to the attached Bidders Activity Report (BAR), Forms A and B, and Debar-2 form. The BAR form must be completed and submitted with your bid proposal, along with either Form A or Form B, and Debar-2 form. Failure to submit the Form BAR, appropriate form A or B, and Debar-2 form will cause the bid to be rejected. Completion of the Bidders Activity Report is necessary in order to fulfill the requirements of obtaining a complete list of contractors contacted with regard to this project, in accordance with 49 CFR 26.11c. Statistical information used from the Bidders Activity Report will be used in the calculation of the next year’s DBE goals. By completing Form A, you are advising the City how the contract goal will be met. In the event you believe you will be unable to meet the goals, the attached Form B must be completed and submitted with the Bid Proposal. Please be advised that good-faith efforts will be subjected to close scrutiny and if the good-faith effort submission is unacceptable, your bid will be rejected.

Information regarding a project sign for the Bipartisan Infrastructure Law (BIL) for the State Revolving Fund Programs for BIL-funded projects must be included. Information for the BIL project sign requirements may be found at https://danr.sd.gov/Funding/docs/BIL%20Guidelines.pdf.

The City of Sioux Falls, upon request, shall furnish at least one copy of the plans and specifications, without charge, to each contractor resident in South Dakota who intends, in good faith, to bid upon the public improvement.

A Prebid Conference will be held on Friday, May 22nd, 2026 at 10:00 AM at the City Center Room 110, 231 N Dakota Avenue, Sioux Falls, SD 57104.

Published twice on May 15 & May 22, 2026, at the approximate cost of $138.63, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15 & May 22, 2026

BID REQUEST NO.: 26-1090
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for Pump Station 215 Discharge Piping Replacement.

To participate, you must be registered as a vendor on the e-procurement platform. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, June 4, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

Specifications and bid forms that must be used are available online at siouxfalls.bonfirehub.com. Cite Bid Request No. 26-1090.

It is the bidder’s responsibility to check the e-procurement portal for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

A Prebid Conference will be held on May 26, 2026 at 9:00 a.m. at Pump Station 215, 3301 W. 12th Street, Sioux Falls, SD.

Published twice on May 15 & May 22, 2026, at the approximate cost of $37.70, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15 & May 22, 2026

BID REQUEST NO.26-0074
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for Rock Salt and Transportation.

To participate, you must be registered as a vendor in the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “Register” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the e-procurement portal not later than May 28, 2026, 2 p.m., Central time, . Immediately thereafter, the bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

It is the vendor’s responsibility to check the e-procurement portal website for any changes or updates to the invitation for bid, which will be in the form of an addendum posted to the e-procurement portal website.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on May 15 & May 22, 2026, at the approximate cost of $31.33, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15 & May 22, 2026

BID REQUEST NO. 26-1088
NOTICE TO BIDDERS

The City of Sioux Falls, SD requests formal bids for: Sioux Falls Canaries Stadium - Caulking.

To participate, you must be registered as a vendor on the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, June 4th, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at https://www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the e-procurement poral for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make Award(s) as deemed to be in the best interest of Sioux Falls, SD.

There will be a pre-bid walk-through of the Project held on May 26, 2026 at

11:00 AM. Interested bidders should gather at the North Entry (main entry) of the Canaries Stadium. This is an important meeting for prospective bidders, but it is not a

mandatory prerequisite to submitting a bid.

Published twice on May 15 & May 22, 2026, at the approximate cost of $38.87, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

BID REQUEST NO.: 26-1087
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for 2026 Miscellaneous Drainage Improvements.

To participate, you must be registered as a vendor on the e-procurement platform. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, Thursday, May 28, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the e-procurement portal for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on May 8 & May 15, 2026, at the approximate cost of $33.07, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

BID REQUEST NO.: 26-1063
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for 2026 ADA TRANSITION PLAN PROJECT 1- CURB RAMP IMPROVEMENTS.

To participate, you must be registered as a vendor on the e-procurement platform. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, May 28, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the e-procurement portal for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on May 8 & May 15, 2026, at the approximate cost of $33.65, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

BID REQUEST NO. 26-1042
NOTICE TO BIDDERS

The City of Sioux Falls, SD requests formal bids for: Washington Pavilion – Public Lighting LED Upgrade.

To participate, you must be registered as a vendor on the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, May 28, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at https://www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the e-procurement poral for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make Award(s) as deemed to be in the best interest of Sioux Falls, SD.

A Pre-Bid Meeting is scheduled for 10:00AM on May 18, 2026 at the project site, Washington Pavilion, 301 S Main Avenue, Sioux Falls, SD 57104, to allow bidders the opportunity to review the existing site conditions. Interested bidders should assemble in the first floor lobby. Although attendance is encouraged, it is not a mandatory prerequisite to submitting a bid.

Published twice on May 8 & May 15, 2026, at the approximate cost of $40.03, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

BID REQUEST NO. 26-0073
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for Aluminum Traffic Sign Blanks

To participate, you must be registered as a vendor in the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “Register” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, May 21, 2026. Immediately thereafter, the bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

It is the vendor’s responsibility to check the e-procurement portal for any changes or updates to the invitation for bid, which will be in the form of an addendum posted to the e-procurement portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on May 8 & May 15, 2026, at the approximate cost of $31.33, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

BID REQUEST NO. 26-0072
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for Traffic Signs and Traffic Sign Faces.

To participate, you must be registered as a vendor in the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “Register” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, May 21, 2026. Immediately thereafter, the bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on May 8 & May 15, 2026, at the approximate cost of $31.33, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

BID REQUEST NO. 26-0065
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for a South Reservoir Fill Valve.

To participate, you must be registered as a vendor in the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “Register” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the e-procurement portal not later than 2 p.m., Central time, May 21, 2026. Immediately thereafter, the bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on May 8 & May 15, 2026, at the approximate cost of $31.33, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

BID REQUEST NO. 26-1089
NOTICE TO BIDDERS

The City of Sioux Falls, SD requests formal bids for: SAM Office – Skylight and Clerestory Panels Replacement.

To participate, you must be registered as a vendor on the e-procurement portal. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through the e-procurement portal and will be received by the portal not later than 2 p.m., Central time, May 28, 2026. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at https://www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the e-procurement portal for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the portal.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make Award(s) as deemed to be in the best interest of Sioux Falls, SD.

A Prebid Conference and walkthrough will be held on Tuesday, May 19, 2026 at 2:00pm at the Sioux Area Metro, 500 East Sixth Street, Sioux Falls, South Dakota.

Published twice on May 8 & May 15, 2026, at the approximate cost of $35.97, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

NOTICE OF HEARING—
VACATE PUBLIC RIGHT-OF-WAY

Notice is given that a petition has been filed by the owners of Northeast Quarter (NE 1/4) of the South 1/2 and the South 1/2 of the South 1/2 of Block 2, Haywards Subdivision, Section 23, Township 101 North, Range 50 West of the 5th Principal Meridian, in the City of Sioux Falls, Minnehaha County, South Dakota; North 1/2 of Block 1 and the East Thirteen Feet of the North 1/2 of Block 2 and the entire vacated street lying between and adjacent to such property (Except H-2) Haywards Subdivision, Section 23, Township 101 North, Range 50 West of the 5th Principal Meridian, in the City of Sioux Falls, Minnehaha County, South Dakota; South 1/2 Block 1 (Except Lot H-1) Haywards Subdivision, Section 23, Township 101 North, Range 50 West of the 5th Principal Meridian, in the City of Sioux Falls, Minnehaha County, South Dakota, are requesting the vacation of the north/south 66’ right-of-way lying adjacent to said lots, as shown on Exhibit A.

The Council will consider said vacation at the Carnegie Town Hall, 235 W. Tenth St., at 6 p.m., Wednesday, June 3, 2026.

Any person interested may appear and be heard.

Jermery J. Washington,

City Clerk

Date: May 5, 2026

Published twice on May 8 & May 15, 2026, at the approximate cost of $29.00, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

NOTICE OF HEARING—
VACATE PUBLIC RIGHT-OF-WAY

Notice is given that a petition has been filed by the owners of Lot 12, 13, 14, and the south 6 feet of Lot 15 in Block 26, Covell’s 2nd Addition to the City of Sioux Falls, lying north of the right-of-way of the Chicago, Saint Paul, Minneapolis, and Omaha Railroad, Minnehaha County, South Dakota, according to the recorded plat thereof and Lot 5 thru 9, Block 26 of Covell’s 2nd Addition to the City of Sioux Falls, lying north of the right-of-way of the Chicago, Saint Paul, Minneapolis, and Omaha Railroad, Minnehaha County, South Dakota, according to the recorded plat thereof, requesting the vacation of a portion of the 16-foot alley in Covell’s 2nd Addition, as shown on Exhibit A.

The Council will consider said vacation at the Carnegie Town Hall, 235 W. Tenth St., at 6 p.m., Wednesday, June 3, 2026.

Any person interested may appear and be heard.

Jermery J. Washington,

City Clerk

Date: May 5, 2026

Published twice on May 8 & May 15, 2026, at the approximate cost of $24.37, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

PUBLISH: May 8 & May 15, 2026

PUBLISH: May 15, 2026

ORDINANCE NO. 35-26

AN ORDINANCE OF THE CITY OF SIOUX FALLS, SD, REZONING PROPERTY LOCATED AT 3001 N. VAN EPS AVE. FROM THE RA-1 APARTMENT RESIDENTIAL—LOW DENSITY DISTRICT TO THE RD-1 TWIN HOME/DUPLEX RESIDENTIAL—SUBURBAN DISTRICT, NO. 22593-2026, AND AMENDING THE OFFICIAL ZONING MAP OF THE CITY OF SIOUX FALLS.

BE IT ORDAINED BY THE CITY OF SIOUX FALLS, SD:

Tracts 13–17 (Except H-Lots), Norton Tracts Subdivision, City of Sioux Falls, Minnehaha County, SD, is hereby rezoned from the RA-1 Apartment Residential—Low Density District to the RD-1 Twin Home/Duplex Residential—Suburban District located at 3001 N. Van Eps Ave., and the official zoning map of the City of Sioux Falls is amended to include the rezoning.

Date adopted: 05/12/26 .

Paul TenHaken, Mayor

ATTEST:

Jermery J. Washington,

City Clerk

Published once on May 15, 2026, at the approximate cost of $12.88, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

MINUTES

City Council Meeting

Tuesday, May 12, 2026, at 6:00 PM

Carnegie Town Hall, 235 West 10th St., Sioux Falls, South Dakota 57104

CALL TO ORDER

1. MEETING ROLL CALL

Present: Council Member Richard L. Thomason, Council Member David Barranco (via tele-com), Vernon Brown, Council Member Rich Merkouris, Council Member Jennifer Sigette, Council Member Curt Soehl, Council Member Ryan Spellerberg, Mayor Paul TenHaken

Absent: Council Member Miranda Basye

2. INVOCATION

• Pastor Erich McCandless, Empire Baptist Temple

3. PLEDGE OF ALLEGIANCE

CONSENT AGENDA

4. APPROVAL OF THE CONSENT AGENDA

A motion was made by Council Member Merkouris and seconded by Council Member Thomason to approve the Consent Agenda.

Roll call vote to approve. 7 Yes: Thomason, Barranco, Brown, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

5. APPROVAL OF MINUTES

• Informational Meeting of Tuesday, May 5, 2026

• City Council Meeting of Tuesday, May 5, 2026

COMMUNICATIONS

6. Approval of contracts/agreements over $100K on the memorandum dated May 8, 2026.

7. Notice of Contracts/Agreements under $100K and Change Orders over $100K through April 30, 2026.

8. Approval of a request pursuant to SDCL 35-1-5.5 from Evan Moore to consume, but not sell, alcoholic beverages at the Mary Jo Wegner Arboretum, 1900 S. Perry Pl., on June 11, 2026.

9. Approval of a request pursuant to SDCL 35-1-5.5 from JoEllen Evavold to consume, but not sell, alcoholic beverages at the Mary Jo Wegner Arboretum, 1900 S. Perry Pl., on June 18, 2026.

APPLICATIONS

10. Special One-Day Liquor License for T Slat Inc., to be operated at the Old Courthouse Museum, 200 West 6th Street, for a wedding on May 16, 2026.

11. Special One-Day Malt Beverage License for BLRR Sioux Falls LLC to be operated on Lake Lorraine, 2400 South Lorraine Place, for a hobby horse relay on June 20, 2026.

12. Various Retail Malt Beverage renewals for 2026-2027 to be operated at locations in the City of Sioux Falls, SD, identified as Exhibit B.

REGULAR AGENDA

13. APPROVAL OF THE REGULAR AGENDA

A motion was made by Council Member Merkouris and seconded by Council Member Thomason to approve the Regular Agenda.

Roll call vote to approve. 7 Yes: Thomason, Barranco, Brown, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

INTRODUCTION AND ADOPTION OF ORDINANCES

ORDINANCE SECOND READINGS

14. 2nd Reading: Deferred from the Meeting of Tuesday, May 5, 2026; AN ORDINANCE OF THE CITY OF SIOUX FALLS, SD, REZONING PROPERTY LOCATED AT 3001 N. VAN EPS AVE. FROM THE RA-1 APARTMENT RESIDENTIAL—LOW DENSITY DISTRICT TO THE RD-1 TWIN HOME/DUPLEX RESIDENTIAL—SUBURBAN DISTRICT, NO. 22593-2026, AND AMENDING THE OFFICIAL ZONING MAP OF THE CITY OF SIOUX FALLS. The Planning Commission recommends approval (4-0).

Private Applicant(s): Ehrhart Griffin & Associates – Shannon Johnson

A motion was made by Council Member Spellerberg and seconded by Council Member Thomason to adopt Ordinance No. 35-26.

Roll call vote to adopt. 6 Yes: Thomason, Barranco, Brown, Merkouris, Sigette, Spellerberg; 0 No: (None). Motion Passed. Soehl was excused from the meeting and the vote on this item pursuant to City Ordinance 30.017.

HEARINGS AND RESOLUTIONS

15. RESOLUTION ADVISING AND GIVING CONSENT TO THE APPOINTMENT OF MEMBERS TO CERTAIN CITIZEN BOARDS.

Sponsor: Mayor

A motion was made by Council Member Thomason and seconded by Brown to adopt Resolution No. 55-26.

Roll call vote to adopt. 7 Yes: Thomason, Barranco, Brown, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

RESOLUTION NO. 55-26

RESOLUTION ADVISING AND GIVING CONSENT TO THE APPOINTMENT OF MEMBERS TO CERTAIN CITIZEN BOARDS.

BE IT RESOLVED BY THE CITY OF SIOUX FALLS, SD:

That it gives its advice and consent to the following Mayoral appointments:

Name Board Term

Bradley Jans Planning Commission Appointed for a term from June 2026 to June 2031.

Ryan Olson Planning Commission Appointed for a term from June 2026 to June 2031.

Michelle Erpenbach Regional Emergency Medical Services Authority (REMSA) Reappointed for a term from August 2026 to August 2031.

Date adopted: 05/12/26 .

Paul TenHaken, Mayor

ATTEST:

Jermery J. Washington, City Clerk

NEW BUSINESS

There was none.

GENERAL PUBLIC INPUT

Public Input was given on the following: mass surveillance systems, making good decisions, paying attention to noxious needs, and testing the soil around the Smithfield location.

ADJOURNMENT

A motion was made by Council Member Thomason and seconded by Council Member Spellerberg to adjourn the meeting at 6:12 p.m.

Voice vote to adjourn. 7 Yes: Thomason, Barranco, Brown, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

Tamara Jorgensen, MMC, Assistant City Clerk

Published once on May 15, 2026, at the approximate cost of $60.61, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

SIOUX FALLS SCHOOL DISTRICT

PUBLISH: May 15 & May 22, 2026

ADVERTISEMENT FOR BIDS

Publish Dates: May 15th & 22nd

Sealed bids for Cargo Lifts (CNS) PD #3550, will be received at the Central Services Center, Purchasing Department, 1101 North Western Avenue, Sioux Falls, South Dakota, 57104, up until 11:00 AM, Tuesday, June 2, 2026. Bids will be publicly opened, read, and tabulated 11:00 AM of said day in the Central Services Center. Bids will be presented to the School Board at the next succeeding regular Board meeting, all in accordance with Board policy. Specifications and Bid Forms may be obtained at https://www.sf.k12.sd.us/page/pending-bids-and-request-for-proposals or the Purchasing Department in the Central Services Center, 1101 North Western Avenue, Sioux Falls, South Dakota. All bids and contracts shall be made in accordance with and subject to SDCL 5-18A, 5-18B, 5-18C, 5-18D, 5-21, 5-22 and the provisions set forth in the specifications. The School Board reserves the right to reject any and all bids or parts thereof, and to waive any irregularities. School Board, Sioux Falls School District 49-5 of Minnehaha County, South Dakota. By: Todd Vik, Business Manager. This notice may be viewed free of charge on a 13 statewide public notice website maintained pursuant to § 17-2-1.

Published twice on May 15 & May 22, 2026, at the approximate cost of $30.75, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15 & May 22, 2026

ADVERTISEMENT FOR REQUEST FOR PROPOSALS

Publish Dates: May 15th & 22nd Sealed Proposals for Bakery Products (CNS) RFP PD #3544 will be received at the Central Services Center, Purchasing Department, 1101 North Western Avenue, Sioux Falls, South Dakota, 57104, up until 11:00 AM, Monday, June 1, 2026. Proposals will be publicly opened at 11:00 AM of said day in the Central Services Center. Proposals will be presented to the School Board at the next succeeding regular Board meeting, all in accordance with Board policy. Specifications and Bid Forms may be obtained at https://www.sf.k12.sd.us/page/pending-bids-and-request-for-proposals or the Purchasing Department in the Central Services Center, 1101 North Western Avenue, Sioux Falls, South Dakota. All bids and contracts shall be made in accordance with and subject to SDCL 5-18A, 5-18B, 5-18C, 5-18D, 5-21, 5-22 and the provisions set forth in the specifications. The School Board reserves the right to reject any and all bids or parts thereof, and to waive any irregularities. School Board, Sioux Falls School District 49-5 of Minnehaha County, South Dakota. By: Todd Vik, Business Manager. This notice may be viewed free of charge on a 13 statewide public notice website maintained pursuant to § 17-2-1.

Published twice on May 15 & May 22, 2026, at the approximate cost of $30.17, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

ADVERTISEMENT FOR BIDS

Publish Dates: May 8th & 15th

Sealed bids for Music Instruments 2026-27 PD #3549 will be received at the Central Services Center, Purchasing Department, 1101 North Western Avenue, Sioux Falls, South Dakota, 57104, up until 11:00 AM, Thursday, May 28, 2026. Bids will be publicly opened, read, and tabulated 11:00 AM of said day in the Central Services Center. Bids will be presented to the School Board at the next succeeding regular Board meeting, all in accordance with Board policy. Specifications and Bid Forms may be obtained at https://www.sf.k12.sd.us/page/pending-bids-and-request-for-proposals or the Purchasing Department in the Central Services Center, 1101 North Western Avenue, Sioux Falls, South Dakota. All bids and contracts shall be made in accordance with and subject to SDCL 5-18A, 5-18B, 5-18C, 5-18D, 5-21, 5-22 and the provisions set forth in the specifications. The School Board reserves the right to reject any and all bids or parts thereof, and to waive any irregularities. School Board, Sioux Falls School District 49-5 of Minnehaha County, South Dakota. By: Todd Vik, Business Manager. This notice may be viewed free of charge on a 13 statewide public notice website maintained pursuant to § 17-2-1.

Published twice on May 8 & May 15, 2026, at the approximate cost of $30.17, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

SCHOOL BOARD MEETING

The School Board of the Sioux Falls School District 49-5 of Minnehaha County, South Dakota, was called into special session, pursuant to due notice, on Wednesday, May 6, 2026, at

3:00 p.m. in the Instructional Planning Center, 201 East 38th Street, Sioux Falls, South Dakota, with the following members present: Elizabeth Duffy, Dawn Marie Johnson (arrived at 3:04 p.m.), Gail Swenson, Vice President Marc Murren, and President Nan Kelly. Absent: none. Todd Vik, Business Manager, Dr. James Nold, Superintendent, Daniel Conrad, Assistant Superintendent, and Dr. Kirk Zeeck, Assistant Superintendent, were also present.

The purpose of this work session was to provide updates and have general discussion on the following topics:

Public Input on Agenda Items: none.

Dr. Kirk Zeeck, Assistant Superintendent, went over the Summer Programming. He explained how the Curriculum and Community Learning Centers (CLC) teams have partnered together to create the summer program for academic success. Coordinators and Directors of each department presented an overview of their summer program. This included the departments of Community Education, Community Learning Centers, English Learners & Migrant, Extended School Year & Special Education, Ready to Start, Title I & Spanish Immersion, Elementary, Middle, and High Schools.

Board members gave the following committee reports:

Gail Swenson-McKinney-Vento Homeless

Marc Murren-ASBDA Delegate Legislative Year Wrap-Up

Nan Kelly-Sioux Falls Education Foundation and the Recognition/Retiree Event

Dawn Marie Johnson-Wellness

Elizabeth Duffy-Insurance and Policy Review

Action 39942

On motion by Gail Swenson and seconded by Marc Murren five (5) votes “yes” on roll call, the School Board adjourned at 3:38 p.m.

NAN KELLY

Presiding Officer

TODD VIK

Business Manager

Published once on May 15, 2026, at the approximate cost of $22.91, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

SCHOOL BOARD MEETING

Wednesday, May 6, 2026

The School Board of the Sioux Falls School District 49-5 of Minnehaha County, South Dakota, was called into regular session, pursuant to due notice, on Wednesday, May 6, 2026, at 4:00 p.m. in the Instructional Planning Center, 201 East 38th Street, Sioux Falls, South Dakota, with the following members present: President Nan Kelly, Marc Murren, Gail Swenson, Dawn Marie Johnson, Elizabeth Duffy.

Action ST01019 A motion was made by Gail Swenson and seconded by Dawn Marie Johnson, five (5) votes “yes” on roll call approving the minutes of meetings held on April 1, 2026, and which were furnished to the Sioux Falls Argus leader for publication, in unapproved form, all in accordance with SDCL §13-8-35.

Action ST01020 A motion was made by Marc Murren and seconded by Dawn Marie Johnson, five (5) votes “yes” on roll call, approving the agenda as presented.

President Kelly asked about any conflicts of interest. None were brought forward.

Action ST01021 A motion was made by Dawn Marie Johnson and seconded by Gail Swenson, five (5) votes “yes” on roll call, approving Item A through D on the consent agenda as follows:

A. Approval of Bid Award - Wells Fargo Homebuilding Lab Construction

Acknowledging the administration’s report of the study of bids which were received on Tuesday, April 28, 2026 at 11AM CT, at Southeast Technical College Hub building and approving the bid of the lowest responsible bidder, as follows:

Southeast Technical College House Construction Lab Proposal to be awarded to VanBuskirk Construction Company for their lowest responsible base bid amount of $3,275,000 with a possible classroom additional bid of $1,500,000 with the total bid of $4,775,000, which was $286,220 lower than the next highest total bid received (MRF #ST742).

B. Approving the Authorizations and Ratifications, as follows:

B.1. Approval of Contracts

Authorizing the President to enter into and execute contracts, for and on behalf of the Southeast Technical College, as follows:

Item Contract Number Contractor Project Cost

B.1.a STC26-005 Concourse Syllabus Academic syllabus software 5-year agreement $28,400

B.2. Approval of Purchase Orders

Authorizing the Business Manager to issue Purchase Order(s) requiring additional approval of the School Board as follows:

Item PO No. Vendor Description Total Cost

B.2.a. 2604892 OPTO International Inc New Counters, Fixtures, and Fitting Room for Bookstore Operations $85,046.28

B.2.b S2605052 Riverside Technologies Inc. Faculty Tablets - HP Flip 8 G2I 16GB (6)

Faculty Refresh – HP 4 16 Inch G2A (40) $60,128.00

B.3. Approval of Disposal of District Property

Authorizing the disposal of surplus to sell at private sale, public auction, or sealed bids or to dispose of, in accordance with SDCL§6-13-1, as follows:

Item No. Description Location Appraisers Appraised Value Property File No.

B.3.a Steel Ramp STC Erin Paradise Kevin Shotkoski Patricia Spicer $100 STC - 021

C. Approving the Consolidated Report of Trust and Agency Funds of May 6, 2026, and stating for the record that as of March 31, 2026, receipts total $47,216,085.29 and disbursements total $41,588,376.61.

D. Accepting the Southeast Tech Personnel Report, as follows:

D1. Resignations. Accepting the resignation of School District Personnel as of the effective date indicated, the personnel having been previously employed by Board Action, as follows

Name Location/Position Effective Date

Employee, Full-Time, Hourly

Shaw, Andrew Custodian 04-09-26

Employee, Full-Time, Salaried

Oswald, Vicki President’s Office 04-03-26

D2. Employment Recommendations

Name Location/Position Effective Date Amount

Instructor, Adjunct, Hourly

Gile, Natalya Nursing & Health 05-04-26 $46.00

Odland, Kristin Nursing & Health 05-04-26 $46.00

Student Help, Part-Time, Hourly

Zenobi, Edward Engineering 04-13-26 $20.00

Hert, Eva Engineering 04-13-26 $20.00

Employee, Full-Time, Salaried

Ketcham, Claire Nursing Instructor 05-04-26 $10,912.58

186-Day, 1.0 FTE

Level 5, Step 7

30 days prorated

D3. Employee Lump Sum Payment/Stipend

Name Location/Position Effective Date Amount

Schuette, Amanda Foundation 05-01-26 $500.00

VanBriesen, Tonya Finance 05-01-26 $500.00

Beck, Kelly Nursing & Health 05-01-26 $500.00

Larson, Jim Finance 05-01-26 $500.00

Action ST01022 Instructor Loretta Leloux presented an update on the academic Early Childhood program at Southeast Technical College. (MRF #ST744). The Early Childhood Specialist Program pursues excellence and focuses on student learning based on the development of children from prenatal through age 8. Our educational experiences give students the opportunity to develop hands-on, critical thinking, and personal skills required to care for young children and their families. Students will learn practices that foster collaboration, age-appropriate curriculum, and developmentally appropriate teaching skills in a nurturing environment. Our early childhood courses are designed to provide real-life application and professional learning experiences to prepare students to be confident and competent early childhood professionals. Program accomplishments, highlights, technical skills needed to obtain an industry position, student service opportunities, and data were shared.

Following general discussion, a motion was made by Marc Murren and seconded by Gail Swenson, five (5) votes “yes” on roll call to acknowledging the Early Childhood Academic Program Report.

Action ST01023 STC Program Lead, Chelsea Unzicker presented on the academic Phlebotomy Technician program at Southeast Technical College. (MRF #ST745 The Southeast Technical College Phlebotomy Technician Certificate Program became a one semester certificate in the 2020-2021 academic year. This change created a shorter training option for students while also helping to meet the need for phlebotomy technicians in healthcare. Students in the certificate program learn skills such as blood collection, specimen handling, infection control, patient communication, and safety procedures. The program includes classroom learning and hands-on practice to prepare students for an entry-level job in the healthcare setting including hospitals, clinics, and laboratories. The one-semester program provides students with a quick path to the workforce which has also served as a starting point for students who are interested in other healthcare careers. The program supports current workforce needs and provides students with training for jobs in the community.

Following general discussion, a motion was made by Elizabeth Duffy and seconded by Gail Swenson, five (5) votes “yes” on roll call to acknowledge the Phlebotomy Technician Program Report.

Action ST01024 Vice President of Finance Christine Goldsmith provided the Proposed FY27 Budget report (MRF# ST746). The report highlighted a proposed total budget of $61 million, which includes approximately $19 million dedicated to construction and facility remodeling. This represents an overall budget increase of 2.9% compared to the prior year. Additionally, the proposal includes a 3% salary increase for all faculty and staff, excluding adjuncts, and a one-time increase of approximately 60% in state-funded equipment grants.

Following general discussion, a motion was made by Gail Swenson and seconded by Marc Murren, five (5) votes “yes” on roll call acknowledging the proposed FY27 budget and schedule the public hearing for the final budget during the June 2026 meeting.

Action ST01025 A motion was made by Gail Swenson and seconded by Dawn Marie Johnson, five (5) votes “yes” on roll call, approving the second reading Sioux Falls School District/STC policies/regulations (MRF #ST747), as follows:

A. STC 535 – Equal Opportunity, Harassment and Nondiscrimination

Action ST01026 A motion was made by Gail Swenson and seconded by Elizabeth Duffy, five (5) votes “yes” on roll call, approving the review/revise or withdrawal of policies and accompanying regulations (MRF #ST748), as follows:

A. STC 105 – nondiscrimination/Equal Opportunity – Withdrawal

B. STC 706 – Harassment - Withdrawal

C. STC 910 – Harassment - Withdrawal

D. STC 914 – Student Sex/Gender Harassment, Discrimination, and Misconduct – Withdrawal

Action ST01027 On motion by Marc Murren and seconded by Dawn Marie Johnson, five (5) votes “yes” on roll call, the School Board adjourned at 4:59 p.m.

NAN KELLY

Presiding Officer

TODD VIK

Business Manager

Published once on May 15, 2026, at the approximate cost of $101.50, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

CITY OF BALTIC

PUBLISH: May 15, 2026

NOTICE OF PUBLIC HEARING

Pursuant to SDCL 11-4-4, notice is hereby given that the Baltic Planning & Zoning Commission will hold a public hearing on Wednesday, May 27 ,2026 at 6pm regarding a Variance request at 302 Douglas Blvd to extend the driveway by 12ft.

A copy of the request is available for public review at the Baltic City Hall in the office of the Finance Officer during regular business hours.

The public hearing will be held at the following time, date, and location:

6:00 p.m.

MAY 27, 2026

Baltic City Hall (130 St. Olaf Street)

The Baltic City Council invites all interested persons to attend and offer their comments. Those interested persons not able to attend are invited and encouraged to send written comments, prior to the hearing, to the Baltic Finance Officer, PO Box 327, Baltic, SD 57003.

In compliance with the Americans with Disabilities Act (ADA), if you need special assistance to participate in this hearing, please contact the Finance Officer at (605) 529-5497. Anyone who is deaf, hard-of-hearing or speech-disabled may utilize Relay South Dakota at (800) 877-1113 (TTY/Voice). Notification 48 hours prior to the hearing will enable the city to make reasonable arrangements to ensure accessibility to this hearing.

Lauren Utecht

City of Baltic Finance Officer

Published once on May 15, 2026, at the approximate cost of $18.04, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 22 & May 29, 2026

NOTICE OF VACANCY
MUNICIPALITY OF BALTIC, SOUTH DAKOTA

The following offices will become vacant due to the expiration of the present term or due to the resignation of office of the elective officer:

Mayor, 4-year term

City Council, Alderman-Ward 1, 4-year term

City Council, Alderman-Ward 2, 4-year term

Circulation of nominating petitions may begin on July 3, 2026, and petitions may be filed in the office of the finance officer located at 130 St Olaf Ave, Baltic SD, between the hours of 9 a.m. and 4p.m. central standard time not later than the 27th day of August, 2026, or mailed by registered mail not later than the 27th day of August 2026, at 5:00 p.m. central standard time.

Lauren Utecht

Finance Officer

Source: 4 SDR 26, effective October 27, 1977; 8 SDR 24, effective September 16, 1981; 14 SDR 19, effective August 9, 1987; 16 SDR 20, effective August 10, 1989; 19 SDR 12, effective August 5, 1992; 42 SDR 178, effective July 1, 2016; 47 SDR 37, effective October 6, 2020.

General Authority: SDCL 12-1-9(3).

Law Implemented: SDCL 9-13-6, 9-13-7, 9-13-9.

Published twice on May 15 & May 22, 2026, at the approximate cost of $29.00, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

LINCOLN COUNTY

PUBLISH: May 8 & May 15, 2026

NOTICE OF PUBLIC HEARING

NOTICE IS HEREBY GIVEN That the Board of Lincoln County Commissioners will meet in the Courthouse at Canton, South Dakota, on May 26, 2026, and hold a public hearing between 6:30 p.m. and adjournment, pursuant to SDCL 7-21-22, for the purpose of adopting the following supplements to the 2026 Budget: A supplement adding to the Highway Fund Road Construction account 201-4311-429200 in the amount of $3,926,524.00 per resolution 2405-20 passed on 05/7/2024, a supplement adding to account 201-4311-37100 in the amount of $3,926,524.00 per resolution 2405-20 passed on 05.07.2024, a supplement increasing 101-4911-000000 in the amount of 3,926,524.00, a supplement increasing 295-4311-422000 by 600,000.00 for grant funding that was approved the Rural Access Infrastructure (RAIF) process.

The public hearing is open to all interested parties. Anyone unable to attend the public hearing can submit written comments to the Lincoln County Auditor at 104 N. Main Street, Suite 110, Canton, SD 57013. Written comments will be reported to the County Commission on the date of the hearing. Individuals needing special accommodations are asked to contact the Lincoln County Auditor at least 48 hours prior to the hearing. Any interested person may appear either in person or by a representative.

Dated this 28th day of April 2026.

Sheri Lund

Lincoln County Auditor

Published twice on May 8 & May 15, 2026, at the approximate cost of $34.23, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

NOTICE OF SALE
OF COUNTY SURPLUS PROPERTY

NOTICE IS HEREBY GIVEN, that Lincoln County will hold a public auction of surplus property at www.publicsurplus.com. The Auction will end on May 18, 2026, the following item will be auctioned:

• Item 1566 2007 Sterling LT9500 2FZHAZDE33AY56842 includes item 1564 2008 Monroe Snow Plow serial number 7121799 and item 1568 2008 Monroe Truck Wing serial number 6086402

• Item 1570 2007 Sterling LT9500 2FZHAZDE57AY56843 includes item 1571 2008 Monroe Snow Plow serial number 7121797 and item 1572 2008 Monroe Truck Wing serial number 6086400

These items will be available for review at www.surplus.lincolncountysd.org

All items are sold as is, where is, and must be removed and payment made as per Public Surplus direction. Additional information may be obtained by contacting Lincoln County Highway Office at 605-764-5841, or by visiting the Public Surplus webpage at www.publicsurplus.com and viewing the sale information.

Dated this 28 of April 2026

Sheri Lund

Lincoln County Auditor

Published twice on May 8 & May 15, 2026, at the approximate cost of $27.85, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

LINCOLN COUNTY BOARD OF COMMISSION
MEETING MINUTES APRIL 28, 2026

THE LINCOLN COUNTY BOARD OF COMMISSIONERS convened at 7PM on April 28, 2026, with Commissioners Joel Arends, Jim Schmidt, Doug Putnam present. Alicia Cafaro, Deputy Auditor, served as Clerk of the Board. Chief Civil Deputy State’s Attorney, Drew DeGroot, was also present.

Vice-Chair, Jim Schmidt, called the meeting to order.

ROUTINE BUSINESS:

MOTION by Joel Arends and seconded by Doug Putnam to approve Agenda. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

Payroll: $506,539.64

Commissioner’s $9,064.24; FICA 537.89, Medicare 125.80, SDRS 165.83

Elections $937.50; FICA 58.13, Medicare 13.59

Auditor’s $16,396.72; FICA 908.90, Medicare 212.57, SDRS 979.60

Treasurer’s $21,278.37; FICA 1,171.86, Medicare 274.06, SDRS 1,269.51

States Attorney’s $89,669.99; FICA 5,201.89, Medicare 1,216.57, SDRS 5,294.89

Gen Gov Bldg $19,845.63; FICA 1,098.97, Medicare 257.02, SDRS 1,179.03

DOE $43,596.58; FICA 2,471.48, Medicare 578.01, SDRS 2,546.63

ROD $10,900.23; FICA 601.71, Medicare 140.72, SDRS 648.31

VSO $2,453.87; FICA 143.24, Medicare 33.50, SDRS 145.73

GIS $6,150.72; FICA 341.24, Medicare 79.81, SDRS 366.35

IT $12,268.84; FICA 728.93, Medicare 170.48, SDRS 731.93

HR $6,340.56; FICA 362.34, Medicare 84.74, SDRS 377.74

Sheriff’s $127,448.71; FICA 7,406.35, Medicare 1,732.13, SDRS 9,390.83

Jail $19,513.73; FICA 1,137.60, Medicare 266.05, SDRS 1,198.89

County 4-H $4,886.15; FICA 288.15, Medicare 67.39, SDRS 290.47

Weeds $4,576.84; FICA 283.76, Medicare 66.36, SDRS 274.60

P & Z $12,769.71; FICA 776.16, Medicare 181.52, SDRS 766.19

Highway $53,178.51; FICA 3,067.36, Medicare 717.37, SDRS 3,053.50

Communications $35,256.88; FICA 2,025.44, Medicare 473.69, SDRS 2,085.86

EM MGMT $4,252.67; FICA 241.04, Medicare 56.37, SDRS 252.16

Airport $3,057.83; FICA 189.59, Medicare 44.34, SDRS 183.47

24/7 $2,695.36; FICA 167.11, Medicare 39.08, SDRS 215.62

Reports:

March 2026 Auditor’s Account with the Treasurer and Financial Reports

MOTION by Joel Arends and seconded by Doug Putnam to move Consent Agenda items 4, 5, 8, 11 and 12 to the end of Regular Business and approve Consent Agenda items. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

CONSENT AGENDA:

MOTION by Joel Arends and seconded by Doug Putnam to approve County Commission Minutes: 04.14.2026. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve Lincoln County Claims in the amount of: $1,907,074.79; GENERAL: Aj’s Automotive LLC, 23-6 Oil Change , 78.84; All Nations Interpreters Inc, Interpreter, 1,473.10; Alvine Law Firm, LLP, Crt Appt Atty, 450.6; Anderson, Jennifer Marie, Mi Evals, 3802.45; Avera , Sane Exam, 1827.53; Baloun Law, Pc, Crt Appt Atty-Juv, 1,080.62; Bast, Krista, Deadwood Per Diem , 48; Benco Products Inc, Supplies, 395.45; Bomgaars, Acct #67-042-3, 231.94; Brown, Chad, Deadwood Conference, 48; Canton Home & Farm Supply, Acct # 319, 951.9; Carlson, Joe, Deadwood Conference 2026, 46; Century Business Products, Auditor Copier Contract, 392.61; Cintas (First Aid), Customer #21078014, 191.67; City Of Harrisburg, March Fuel From Public Works Fuel Tank , 7,624.26; City Of Sioux Falls, Traffic Sign Damaged At S Western Ave & W Veterans, 115.45; Colshan, E.J., Deadwood Conference 2026, 88.67; Coomes, Sue Ann, Mi Hearing, 128; Correct Rx Pharmacy Services Inc, Inmate Prescription , 7.33; Dakota Law Firm Prof LLC, Crt Appt Atty-Juv, 945.6; De Castro Law Office, PLLC, Crt Appt Atty, 6,675.00; Fox Law Firm PLLC, Mi Board-Yankton, 207.57; Grainger, Acct #879306108, 12.29; Griese Law Firm, Pc, Crt Appt Atty, 900; Harrisburg Ace Hardware, Customer #17458, 32.99; Hughes Co Jail, March 2026 -Housing, 115; Jack’s Uniforms & Equipment, Cuffs, 160.75; Jena Skorczewski, Court Reporter, Transcripts, 1,945.30; Jurors/Witnesses, Fees And Mileage, 1724.2; Jw Niederauer Inc, Customer #17458, 73.64; Kading, Kunstle & Goodhope LLP, Crt Appt Atty-Juv, 1556.8; Karla Salem, Qmhp, Mi Evals, 1,852.50; Katie Johnson PLLC, Crt Appt Atty-Juv, 7,560.00; Katterhagen, Mark, Mi Hearing-Yankton, 24; Lamb Chevrolet & Implement Inc, 2026 Chevrolet Equinox , 30,646.00; Larson, Valerie, Mi Hearing-Yankton, 24; Lennox Area Ambulance, Transport - Lc26-90, 460; Lennox Independent LLC, Publishing Tea Weekly & Lennox Independent -, 3337.96; Midwest Alarm Co Inc, Dmp-9646 Lincoln County Courthouse, 478.5; Minnehaha County Jail, Blood Draws, 600; Motorola Solutions Inc, Apx 4500 Radios Mobile Radio Apx4500 Enhanced Vhf , 6,719.32; Napa Auto & Truck Parts Of Sioux Falls, Wo1591, 16.49; Newvision Automotive LLC, 25-6 Tahoe Windshield , 525; Nutrien Ag Solutions Inc, Mec Amine-D And Snapshot, 270; O’leary Law Office, Crt Appt Atty, 2310.09; Pat Beck, Court Reporter, Gj Transcript, 202.5; Phillip Loving, Mi Evals, 6,680.72; Pro Flooring, Asst. Hwy Superintendent Floor Project, 851.65; Redwood Toxicology Laboratory, Lab Testing, 29.56; Rent-All Inc, Customer #41130, 275; Samp Law Office , Crt Appt Atty-Juv, 1,123.20; Sanford Health, Coroner Services, 10,455.00; Sd Dept Of Game, Fish & Parks, Animal Damage Control, 1,019.08; Sd Div Of Motor Vehicle, Special Plates Section, 25.7; Sdaao, 2026 Sdaao Conference , 2,700.00; Sdacc, Quarter 2 - Clerp 2026, 31,555.00; Sioux Falls Rubber Stamp, Stamp, 24.45; Sisson Printing Inc, Tradeshow Note Pad, 459.58; Stephanie Moen & Associates, Gj Transcript, 530; Stitches, Uniform Shirts, 420; Streicher’s, 3 Ball. Shield: Wsca Entry 1 Fr 3 Light Bar , 9,763.75; Sturdevant’s Auto Value, Front Right Wiper Bl 23-6, 49.98; Swenson, Steven, Deadwood Conference2026, 48; Tanner, LLC , Poor Relief-Rent, 900; Terri Lembcke Schildhauer, Rpr, Gj Transcript, 58.5; The Commons LLC, Poor Relief-Rent, 700; The Dakota Scout LLC , Publishing The Dakota Scout -, 1314.17; The Rowe At 57th LLC, Poor Relief-Rent, 690.02; Theisen, Dean, Bar Dues, 415; Thomson Reuters-West Publ Corp, Online Subscription Charges, 966.55; Tiresandmore, 21-5 Oil Change, 3253.61; Tripp County , Difficult Assessments Workshop, 330; Turnwell Mental Health Of South Dakota, Pc, Forensic Insanity Evaluation, 9,300.00; Van Beek Linda , Mi Hearing, 154; Ver Beek Law Prof LLC, Crt Appt Atty-Juv, 5,427.71; Well365, LLC, Online Wellness Portal Online Wellness Portal, 2,780.00; Wernke, Laurie A, Mi Hearing, 53.33; Workforce-South, New Employee Screenings, 280; Yankton Co Sheriff’s Office, Mi Served-Yankton, 50; ROAD AND BRIDGE FUND: Bomgaars, Wo1596,Supplies, 42.29; Buckneberg, Ryan, Cdl Test And License, 205; Bx Civil & Construction Inc, 26.Rab Pay App 1, 85,449.78; Cintas (First Aid), First Aid Supplies, 101.55; Cintas Corp, Uniform, Mats, Towels, 168.91; Crafco, Inc, Wo1586, 7,660.00; Diesel Machinery Inc, Wo1520, 586.5; Dockendorf Equipment Co Inc, Fuel Pumps, 489.64; Feiler, Laurie D, 26.Rab Row Agreement, 18,762.38; Grainger, Supplies, 64.46; Harris, Warren , Cdl For Fed Compliance 2026, 45; Imeg Corp, 27.Tin 143/152, 8,024.30; Kronaizl, Linda, 26.Rab Row Agreement, 1,800.00; Lennox Independent LLC, Publishing Tea Weekly & Lennox Independent -, 84.7; Lincoln Co Treasurer, #13 And #14 Title And Plates, 57.4; Matheson Tri-Gas Inc, Welding Cylinders, 145.08; Mckenzie, Chad, Cdl Fed Update, 45; Midwest Motor Supply Co Inc Dba Kimball Midwest, Earplugs, 749.71; Midwest Petroleum Equipment, Building Air Compressors, 545.07; Napa Auto & Truck Parts Of Sioux Falls, Parts, 671.53; Prochem Dynamics LLC, Custodial Supplies, 759.72; Rockmount Research And Alloys Inc, Cutoff Wheels, 495.41; South Dakota Public Assurance Alliance, #13 And #14 Chassis, 1,628.38; The Dakota Scout LLC , Publishing The Dakota Scout -, 46.4; Tire Motive Service Center, Wo1595, 25; Transwest Trucks Of Sioux Falls, Wo1594, 385; Two Way Solutions Inc, Wo1596,1597, 145.9; Wellman, Waylon, Cdl For Fed Compliance 2026, 45; White, Randall J, 26.Rab Row Agreement, 4,255.70; White, Robert C, 26.Rab Row Agreement, 1,800.00; E911 COMMUNICATIONS: Motorola Solutions Inc, Apx 4500 Radios Mobile Radio Apx4500 Enhanced Vhf, 4,000.00; AIRPORT: MEAD & HUNT, Independent Fee Evaluation, 5,000.00; MODERN/PRESERV/RELIEF: Century Business Products, Monthly Printer/Copy Fees, 60.84; JUSTICE CENTER: Geotek Engineering & Testing Services Inc, 0086079 Lc Justice Center, 248; Jlg Architects, 21030-45 Lc Justice Center, 15,019.88; Henry Carlson Construction LLC, Lc Justice Center 24, 1,503,401.00; Tegra Group, 436.426 Pmt 18 Of 21, 26,496.59; DEBT SERVICE-TIF #8: City Of Harrisburg, Tif #8 Disbursement March 2026, 25,334.87; DEBT SERVICE TIF #9: CITY OF LENNOX, Tif #9 Disbursement March 2026, 11,337.69. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to declare as surplus and remove from inventory the following items from the Highway Department: Item #1566 2007 Sterling LT9500, Item #1570 2007 Sterling LT 9500, Item # 1567 Monroe snow plow, Item #1571 2008 Monroe snow plow, Item #1568 Monroe truck wing, Item #1572 Monroe truck wing and authorize the Auditor to advertise and proceed with online auction. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to transfer the following inventory from the Sheriff’s Office to the Auditor’s Office: Item# 7316, 2021 Chevy Tahoe, VIN#: 1GNSKLED8MR474660. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the Clerk and Treasurer oath and bond for Brooklyn Township and bond for Norway Township. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to award the 2026 micro surfacing bid to ASTECH for $888,980.17. No other bids were submitted. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the hire of Corissa Tuschen, 4-H Summer Assistant, in the 4-H Department, effective 05/26/2026, TEMP at $17.00/hr. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the hire of Allison Oldenkamp, Deputy Sheriff, in the Sheriff’s Office, effective 05/04/2026, SO1/1 at $31.86/hr. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the Step Increase for April Farmer, Appraiser, in the Department of Equalization, effective the first date of the biweekly pay period following 05/06/2026, 108/8 at $34.15/hr. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the Matrix Adjustment for Chad Brown, Chief Deputy, in the Sheriff’s Office, effective 05/03/2026, SO4/13 at $5,673.08 biweekly to 116/10 at $5,712.01 bi-weekly. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the Matrix Adjustment for Benjamin Lord, Captain, in the Sheriff’s Office, effective 05/03/2026, SO3/10 at $4,788.05 bi-weekly to 115/7 at $4,822.07 bi-weekly. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the Matrix Adjustment for Jarid Espland, Captain, in the Sheriff’s Office, effective 05/03/2026, SO3/8 at $4,555.68 bi-weekly to 115/5 at $4,589.79 bi-weekly. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the Correction for Connor Jackson, Equipment Operator, in the Highway Department, effective the first date of the biweekly pay period following 04/21/2026, HWY1/2 at $26.54/hr. *Note: No change in rate, this is an effective date change only. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the Step Increase for Amanda Jeseritz, Victim Witness Legal Assistant, in the State’s Attorney’s Office, effective the first date of the biweekly pay period following 04/21/2026, 108/4 at $30.93/hr. *Note: No change in rate, this is an effective date change only. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to set the date and time for a PUBLIC HEARING on May 26, 2026 between 6:30 p.m. and adjournment, pursuant to SDCL 7-21-22, for the purpose of adopting the following supplements to the 2026 Budget: A supplement adding to the Highway Fund Road Construction account 201-4311-429200 in the amount of $3,926,524.00 per resolution 2405-20 passed on 05/7/2024, a supplement adding to account 201-4311-37100 in the amount of $3,926,524.00 per resolution 2405-20 passed on 05.07.2024, a supplement increasing 101-4911-000000 in the amount of 3,926,524.00, a supplement increasing 295-4311-422000 by 600,000.00 for grant funding that was approved the Rural Access Infrastructure (RAIF) process. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

REGULAR BUSINESS:

The public hearing that was advertised to be held at this meeting regarding a temporary on-sale liquor license was cancelled by the applicant.

COMMISSIONER BRIEFING: Terry Fluit, Highway Superintendent, presented to the Board a resolution regarding the implementation of the Safe Streets for All (SS4A) plan and introduced Sam Trebilcock of Houston Engineering to explain the plan in more detail. Mr. Trebilcock also introduced Kyle Ten Napel, also of Houston Engineering, to present more information. No public input was heard.

MOTION by Joel Arends and seconded by Doug Putnam to approve the following resolution:

A RESOLUTION OF THE LINCOLN COUNTY, SD BOARD OF COMMISSIONERS AUTHORIZING AND SUPPORTING THE DEVELOPMENT AND IMPLEMENTATION OF A SAFE STREETS FOR ALL (SS4A) COMPREHENSIVE SAFETY ACTION PLAN

WHEREAS, traffic fatalities and serious injuries represent a significant public health concern nationally, statewide, and locally, with rural counties experiencing disproportionately high rates of fatal and serious crashes; and

WHEREAS, the United States Department of Transportation’s Safe Streets and Roads for All (SS4A) program, established through the Infrastructure Investment and Jobs Act (IIJA), provides federal funding to support the development and implementation of comprehensive, data-driven roadway safety plans aimed at eliminating traffic-related deaths and serious injuries; and

WHEREAS, a Comprehensive Safety Action Plan is required to identify high-injury networks, analyze crash data, elevate community input, and prioritize evidence-based strategies to reduce and ultimately eliminate fatal and serious traffic crashes; and

WHEREAS, a countywide Comprehensive Safety Action Plan has enabled Lincoln County to establish clear safety goals, performance measures, equity considerations, and implementation strategies that reflect local needs across incorporated and unincorporated areas; and

WHEREAS, adoption of this Resolution demonstrates Lincoln County’s commitment to roadway safety and its willingness to dedicate staff time, technical resources, and leadership support to the planning and implementation process; and

WHEREAS, approval of this Resolution satisfies the requirement for formal governing body commitment as part of an application for SS4A Planning, Implementation and Demonstration Grant funding.

NOW, THEREFORE, BE IT RESOLVED BY THE LINCOLN COUNTY BOARD OF COMMISSIONERS:

1. Authorization

The Lincoln County Board of Commissioners hereby approves the Lincoln County Safe Streets for All Comprehensive Safety Action Plan consistent with SS4A program requirements.

2. Commitment to Safety Goals

The County commits to goal of a 50% reduction of traffic-related fatalities and serious injuries by 2036, supported by data-driven analysis and a Safe System framework. A review of the goals should occur each year to take into consideration significant changes in traffic volumes and population growth

3. Outcome-based safety metrics

The County will monitor three outcome-based safety metrics as evidence of progress to reaching their safety goals including:

• Annual number of roadway fatalities and serious injuries (KSI).

• Five year rolling averages for fatalities and serious injuries to smooth annual variability.

• Changes in crash frequency and severity along the High-Injury Network.

4. Designation of Responsible Authority

The Lincoln County SS4A Study Advisory Team is authorized to monitor the implementation of this Resolution and the SS4A Comprehensive Safety Action Plan.

ADOPTED this 28th day of April, 2026. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

COMMISSIONER BRIEFING: Drew DeGroot, Deputy Civil State’s Attorney, presented the information to the Board regarding new hangar lease agreements that will be heard before a public hearing at the next evening meeting. No public input was heard.

MOTION by Joel Arends and seconded by Doug Putnam to set the date and time for a PUBLIC Hearing to occur between 6:30 p.m. and adjournment of the May 26, 2026, Board of Commissioners Meeting regarding the intent to enter into a lease with multiple properties for a term exceeding 120 days and an amount exceeding $500.00 at the Marv Skie/ Lincoln County Airport. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

COMMISSIONER BRIEFING: Steve Swenson, Lincoln County Sheriff, presented information to the Board regarding the reclassification of two positions in the Sheriff’s Office. No public input was heard.

MOTION by Joel Arends and seconded by Doug Putnam to reclassify vacant S03 position into Grade 116 within Jail Division of the Sheriff’s Office. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Doug Putnam and seconded by Joel Arends to reclassify a current S01 to an SO2 in the Sheriff Department. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

SECOND READING & PUBLIC HEARING was held as advertised for an ordinance of Lincoln County, SD, amending the code of ordinances of the county by changing the zone of a portion (approximately 1.01 acres) of the property described as the east 318.5 feet of the south 375 feet of the south half of the southeast quarter of the southeast quarter (s1/2 se1/4 se1/4) (except lot h-1 thereof) of section 15, township 98 north, range 49 west of the 5th p.m., Lincoln County, South Dakota from the C Commercial District to the A-1 Agricultural District and amending the official zoning map of Lincoln County. The Planning Commission recommends approval (5-0-1). Toby Brown, Director of Planning and Zoning, was present to explain the down-zone and to answer questions. The applicant was also present to answer questions. No comments were given by proponents or opponents. No public comment was heard.

MOTION by Joel Arends and seconded by Doug Putnam to approve an ordinance of Lincoln County, SD, amending the code of ordinances of the county by changing the zone of a portion (approximately 1.01 acres) of the property described as the east 318.5 feet of the south 375 feet of the south half of the southeast quarter of the southeast quarter (s1/2 se1/4 se1/4) (except lot h-1 thereof) of section 15, township 98 north, range 49 west of the 5th p.m., Lincoln County, South Dakota from the C Commercial District to the A-1 Agricultural District and amending the official zoning map of Lincoln County. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

COMMISSIONER BRIEFING: Drew DeGroot, Chief Civil Deputy State’s Attorney, provided information regarding the 2026044 Lincoln County Airport Application grant application. DeGroot also discussed the tentative award to Black-Top Paving for the AIP project 3-46-0078-025-2026 Hangar Taxilane Expansion in the amount of $357,500.51. There were 5 other bids submitted for this project; Soukup Construction, Inc, Sioux Falls - $378,378.00; LT Companies, Inc, Tea - $432,117.26; Runge Enterprises, Inc, Sioux Falls - $481,966.56; Double H Paving, Tea - $482,046.58; and Metro Construction, Inc, Tea - $485,249.02. Public input was heard.

MOTION by Joel Arends and seconded by Doug Putnam to approve and authorize the chair to sign 2026044 Lincoln County Airport Grant Application in the amount of $590,000. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Joel Arends and seconded by Doug Putnam to approve the tentative award for AIP project 3-46-0078-025-2026 Hangar Taxi Lane Expansion, the Base Bid is made to Black-Top Paving of Tea, SD in the amount of $357,500.51 contingent upon receipt of an FAA Grant Offer. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

OPPORTUNITY FOR PUBLIC COMMENT

Public comments were heard.

COMMISSIONER REPORT (INFORMATIONAL ONLY)

Commissioners gave reports.

EXECUTIVE SESSION:

MOTION by Joel Arends and seconded by Doug Putnam to enter into Executive Session at 8:06 p.m. For the following purposes: Consulting with legal counsel or reviewing communications from legal counsel about proposed or pending litigation or contractual matters. SDCL 1-25-2(3). Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

MOTION by Doug Putnam and seconded by Joel Arends to exit Executive Session at 8:31 p.m. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

ADJOURNMENT

MOTION by Joel Arends and seconded by Doug Putnam to adjourn at 8:31 p.m. until 8:30 a.m. on May 5,2026. Ayes; Joel Arends, Jim Schmidt, Doug Putnam, Nays; None. Motion Passed.

Lincoln County Board of Commissioners

Jim Schmidt,

Lincoln County Vice-Chair

Attest:

Alicia Cafaro,

Deputy Auditor

Published once on May 15, 2026, at the approximate cost of $245.34, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

APRIL 21, 2026
COUNTY BOARD OF EQUALIZATION

THE LINCOLN COUNTY BOARD OF COMMISSIONERS convened as a County Board of Equalization at 8:30 a.m. on April 21, 2026, with Commissioners Tiffani Landeen, Betty Otten, Doug Putnam present, and Joel Arends appeared via telephone. Sheri Lund, Auditor, served as Clerk of the Board.

Tiffani Landeen, Chair, called the meeting to order.

Karla Goossen, Director of Equalization, was present to present appeals and requested actions to the Board.

MOTION by Otten and seconded by Putnam to convene as the County Board of Equalization. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

MOTION by Otten and seconded by Putnam to approve the agenda. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

MOTION by Otten and seconded by Putnam to approve the consent agenda. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

CONSENT AGENDA:

MOTION by Otten and seconded by Putnam to approve County Board of Equalization Minutes; 04.14.2026. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

MOTION by Otten and seconded by Putnam to approve correction from April 14, 2026, motion of periodic review of exempt status Per SDCL 10-4-21, for the listed parcels for assessment year 2026 from 1% exempt to 99% exempt, Parcels 281.19.00.001, 282.05.01.001A. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

MOTION by Otten and seconded by Putnam to approve disabled Veteran Applications that missed the deadline but otherwise would have qualified for the 2026 assessment year per SDCL 10-4-40, 10-4-41: Application 2026-23, Effective 2/13/2025, Received 4/15/2026. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

OPPORTUNITY FOR PUBLIC COMMENT:

No one chose to give comment to the Board at this time.

Objection to Real Property Assessment was presented for parcel number 097.50.03.A100 submitted by Ernest and Joann Stratmeyer for a property located in the Lincoln Township. Appellant was present. MOTION by Putnam and seconded by Arends that the NA-CS be set at $0.00 and the NA-C1-S be set at $0.00 for a total valuation of $0.00. Arends: “Aye” Otten: “Nay” Putnam: “Aye” Landeen; “Nay”. Motion failed.

Objection to Real Property Assessment was presented for parcel number 097.50.03.A100 submitted by Ernest and Joann Stratmeyer for a property located in the Lincoln Township. Appellant was present. MOTION by Otten and seconded by Arends that the NA-CS be set at $20,000.00 and the NA-C1-S be set at $0.00 for a total valuation of $20,000. Arends: “Aye” Otten: “Aye” Putnam: “Aye” Landeen; “Naye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 099.50.03.2010 submitted by Donald and Dawn Hoffman for a property located in the LaValley Township. Appellant was present. MOTION by Otten and seconded by Putnam that the AG-A be set at $180,900 the AG-A1 be set at $40,000 and the NA-A1-S be set at $210,000 for a total valuation of $430,900. Arends: “Aye” Otten: “Aye” Putnam: “Aye” Landeen; “Nay”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 099.50.03.C100 submitted by Benjamin and Katie Keppen for a property located in the LaValley Township. Appellant was present. MOTION by Putnam and seconded by none that the NA-CS be set at $30,600 and the NA-C1-S be set at $404,700 for a total valuation of $435,300. Motion failed for lack of a second.

Objection to Real Property Assessment was presented for parcel number 099.50.03.C100 submitted by Benjamin and Katie Keppen for a property located in the LaValley Township. Appellant was present. MOTION by Otten and seconded by Arends that the NA-CS be set at $60,000 and the NA-C1-S be set at $404,700 for a total valuation of $464,700. Arends: “Aye” Otten: “Aye” Putnam: “Aye” Landeen; “Nay”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 099.50.08.2030 submitted by Calvin Schriver and Wayne and Amy Fischer for a property located in the LaValley Township. Appellant was not present. MOTION by Otten and seconded by Arends that the NA-C be set at $262,100 the NA-C1 be set at $15,562 and the NA-C1 be set at $30,338 for a total valuation of $308,000. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Commissioner Arends left the meeting at 9:46 a.m.

Objection to Real Property Assessment was presented for parcel number 280.23.13.006A submitted by Tan Tara Partners for a property located in the City of Sioux Falls. Appellant was present. MOTION by -Otten and seconded by Putnam that the NA-DC be set at $213,400 and the NA-DC2 be set at $862,850 for a total valuation of $1,076,250. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 100.50.64.K005 submitted by Just Right Storage for a property located in Delapre Township. Appellant was present. MOTION by Otten and seconded by Putnam that the NA-CC be set at $222,500 and the NA-CC2 be set at $501,220 for a total valuation of $723,720. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 250.40.05.4000 submitted by Gene Kuper, Elonda Makins and Gary Kuper for a property located in the City of Lennox. Appellant was not present. MOTION by Otten and seconded by Putnam that the AG-D be set at $461,000 for a total valuation of $461,000. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 260.45.04.003 submitted by S&S Rentals LLC for a property located in the City of Beresford. Appellant was present. MOTION by Otten and seconded by Putnam that the NA-DC be set at $79,906 and the NA-DC2 be set at $466,118 for a total valuation of $546,024. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 260.45.07.002 submitted by S&S Rentals LLC for a property located in the City of Beresford. Appellant was present. MOTION by Otten and seconded by Putnam that the NA-DC be set at $56,900 and the NA-DC2 be set at $412,400 for a total valuation of $469,300. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 260.50.31.005 submitted by 9 Mile SD LLC for a property located in the City of Beresford. Appellant was not present. MOTION by Otten and seconded by Putnam that the NA-DC be set at $116,300 and the NA-DC2 be set at $1,777,300, for a total valuation of $1,893,600. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 270.81.13.035 submitted by Central Park Village LLC for a property located in the City of Harrisburg. Appellant was not present. MOTION by Otten and seconded by Putnam that the NA-D be set at $21,700 and the NA-D1 be set at $200,100 for a total valuation of $221,800. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 280.51.03.005 submitted by Anuvisa LLC for a property located in the City of Sioux. Appellant was present. MOTION by Putnam and seconded by Otten that the NA-DC be set at $835,300 and the NA-DC2 be set at $2,919,600 for a total valuation of $3,754,900. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 280.51.03.006 submitted by Dakota Spirit for a property located in the City of Sioux. Appellant was present. MOTION by Putnam and seconded by none that the NA-DC be set at $389,682 and the NA-DC2 be set at $907,470 for a total valuation of $1,297,152. Motion failed for lack of a second.

Objection to Real Property Assessment was presented for parcel number 280.51.03.006 submitted by Dakota Spirit for a property located in the City of Sioux. Appellant was present. MOTION by Otten and seconded by Landeen that the NA-DC be set at $457,241and the NA-DC2 be set at $899,500 for a total valuation of $1,356,741. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 280.27.00.001A submitted by Holiday Station Stores LLC for a property located in the City of Sioux Falls. Appellant was not present. MOTION by Otten and seconded by Putnam that the NA-DC be set at $831,000 and the NA-DC2 be set at $912,600 for a total valuation of $1,743,600 Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 280.76.04.002A submitted by Holiday Station Stores LLC for a property located in the City of Sioux Falls. Appellant was not present. MOTION by Otten and seconded by Putnam that the NA-DC be set at $1,008,700 and the NA-DC2 be set at $1,092,500 for a total valuation of $2,101,200. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Objection to Real Property Assessment was presented for parcel number 281.83.01.002A submitted by Holiday Station Stores LLC for a property located in the City of Sioux Falls. Appellant was not present. MOTION by Putnam and seconded by Otten that the NA-DC be set at $1,155,200 and the NA-DC2 be set at $1,327,600 for a total valuation of $2,482,800. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

MOTION by Otten and seconded by Putnam to recess County Board of Equalization at 10:34 a.m. Otten: “Aye” Putnam: “Aye” Landeen; “Aye”. Motion carried.

Board of Equalization

Tiffani Landeen,

Lincoln County Chair

Attest:

Sheri Lund, Auditor

Published once on May 15, 2026, at the approximate cost of $105.85, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLIC NOTICE

PUBLISH: May 15, 2026

FORM 6
SOUTH DAKOTA LOTTERY COMMISSION
NOTICE OF PUBLIC HEARING TO ADOPT RULES

A public hearing will be held in Room 412 of the Capitol Building, 500 East Capitol Avenue, Pierre on June 11, 2026, at 9:45 a.m. (CT), to consider the adoption and amendment of proposed Administrative Rules of South Dakota numbered

§§ 48:03:06:01, 48:03:06:04, 48:03:07:01, 48:03:07:10, 48:03:10:01, 48:03:10:02, 48:03:10:03, 48:03:13:01, 48:03:13:02, 48:03:13:03, 48:03:15:01, 48:03:15:03, 48:03:16:01, 48:03:16:02, 48:03:16:03, 48:03:17:01, 48:03:17:06, 48:03:18:01, 48:03:18:03, 48:03:19:01, 48:03:19:03, 48:03:20:03, 48:03:21:01, 48:03:21:02.

The effect of the rules will be the adoption of the updated Millionaire for Life game rules, the adoption of Powerball Xs & Os game rules, and the repeal of obsolete rules.

The reason for adopting the proposed rules is to ensure that retailers can continue selling the Millionaire for Life game, to enable retailers to sell the new Powerball Xs & Os game, and to repeal obsolete rules which helps to keep the rules up to date.

Persons interested in presenting amendments, data, opinions, and arguments for or against the proposed rules may appear in-person at the hearing, or mail or e-mail them to the Department of Revenue, attn: Morgan Maier, 445 East Capitol Avenue, Pierre, SD 57501 and/or Morgan.Maier@state.sd.us. The deadline to submit any such written comments for consideration by the Lottery Commission is June 5, 2026, by 5 p.m. (CT).

After the written comment period, the Lottery Commission will consider all written and oral comments it receives on the proposed rules. The Lottery Commission may modify or amend a proposed rule at that time to include or exclude matters that are described in this notice.

For Persons with Disabilities: This hearing will be located at a physically accessible place. Please contact the Department of Revenue at least 48 hours before the public hearing if you have special needs for which special arrangements can be made by calling (605) 773-3311.

Copies of the proposed rules may be obtained without charge from:

Department of Revenue and rules.sd.gov

445 East Capitol Ave, Pierre SD

Morgan.Maier@state.sd.us

(605) 773-6314

Published once on May 15, 2026, at the approximate cost of $28.66, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

NOTICE OF SALE

May 26th at 1:00 PM

AAA COLLETIONS INC vs LEEYON COOPER & SAMUEL KETTOR

(49CIV23-001443-01)

An Execution of Judgment in the above referenced matter was received by the Minnehaha County Sheriff on February 5th, 2026. The amount of the Judgment is $13,184.00, $240.74 Cost, $1,439.42 Pre-judgment Interest, plus continuing costs and interest, as provided by law. This amount does not include Sheriff’s Office fees and costs related to this matter. The property to be sold pursuant to the Execution is: 2018 DODGE GRAND CARAVAN, VIN 2C4RDGCG3JR360612.

THIS PROPERTY WILL BE AUCTIONED AND SOLD TO THE HIGHEST BIDDER, WITH THE SALE BEING FINAL, SOLD AS IS WITH NO WARRANTIES EXPRESSED OR IMPLIED. CASH IS REQUIRED ON THE DAY OF SALE.

The sale will be held at the Armory Building at the WH LYONS fairgrounds, 100 N. Lyon Blvd, Sioux Falls, Minnehaha County, South Dakota on May 26th, 2026, at 1:00 PM, MICHAEL MILSTEAD, SHERIFF OF MINNEHAHA COUNTY. By: Michael C. Brenden #548, Certified Civil Process Server, 605-978-5533.

Published once on May 15, 2026, at the approximate cost of $15.14, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15 & May 22, 2026

INVITATION TO BID

Thompson Center Roof Replacement

SOUTH DAKOTA STATE UNIVERSITY

OSE # R0326—38X/DEL

Sealed bids will be received by South Dakota State University Facilities & Services, Box 2150, Brookings, South Dakota 57007 until 2:00 PM CT on Tuesday May 26, 2026, for labor and materials for a roof replacement on the Thompson Center on the campus of South Dakota State University, OSE# R0326—38X/DEL.

Contractors please note: There will be an on-site pre-bid meeting at 2:00PM Central Time, Tuesday May 19, 2026. Contractors shall meet at the main doors of Thompson Center, on the campus of South Dakota State University in Brookings, SD. Parking is available on the west side of the building. Each Contractor shall examine the premises and be satisfied as to the existing site conditions before submitting a sealed bid.

Copies of the Plans and Specifications may be obtained by bidders at the office of DesignArc Group, 434 5th Street, Suite 1 phone (605)910-7348 OR at regional builder’s exchanges. Copies of the Plans and Specifications are on file for viewing purposes at the office of Facilities & Service, at South Dakota State University, Brookings, SD 57007. Anyone requesting, reviewing, or copying plans and specifications for this project (such individual is hereinafter referred to as “bidder”) agrees that they are doing so for the sole purpose of submitting a bid on the project. In consideration of the State of South Dakota providing such plans and specifications for the purpose of preparing a bid, bidder further agrees:

1. The plans and specifications are the sole property of the State;

2. Any copies of the plans and specifications obtained from the State or its agent, will be returned to the office of SDSU Facilities & Services immediately after the State provides notice that the bidder will not be awarded a contract, or thirty (30) days after the bid opening for the project, whichever occurs first;

3. Any copies of the plans and specifications made by the bidder will be destroyed immediately after the State provides notice that the bidder will not be awarded a contract, or thirty (30) days after the bid opening for the project, whichever occurs first;

4. If the bidder does not submit a bid, bidder will fulfill the requirements of 2 and 3 above on or before the date of the bid opening;

5. The plans and specifications are to be used only with respect to this project and are not to be used for any other project or purposes other than preparing a bid for this project;

6. The plans and specifications will not be disseminated to any person or entity for purposes other than obtaining pricing information without the express written approval of the State;

7. All information contained in the plans and specifications is confidential; and

8. Should the bidder disseminate the plans and specifications to an individual or entity for purposes of obtaining pricing information, the bidder will require that individual or entity to adhere to the terms set forth herein. The bidder, however, assumes no liability for the misuse of the plans and specifications by such third party or such third party’s failure to comply with the provisions contained herein.

Should the bidder be awarded a contract for construction of the project, bidder does not need to return or destroy plans and specifications until after completion of the project.

Each bid in excess of $50,000.00 must be accompanied by a certified check, cashier’s check or draft in the amount of 5% of the base bid and all add alternates and drawn on a State or National Bank or a 10% bid bond issued by a surety authorized to do business in the State of South Dakota and made payable to the Board of Regents of the State of South Dakota.

South Dakota State University reserves the right to reject any or all bids and to waive any irregularities therein.

Barry Mielke

Facilities & Services

South Dakota State University

Published twice on May 15 & May 22, 2026, at the approximate cost of $84.69, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

COURTS

PUBLISH: May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
MERLE NUSSBAUM,
DECEASED.
49PRO26-000104
NOTICE TO CREDITORS

Notice is given that on May 8, 2026, Jill Nussbaum, whose address is 5540 Nathan Lane N #1, Plymouth, MN 55442, was appointed as personal representative of the estate of Merle Nussbaum.

Creditors of decedent must file their claims within four months after the date of the first publication of this notice or their claims may be barred.

Claims may be filed with the personal representative or may be filed with the Clerk, and a copy of the claim mailed to the personal representative.

Dated this 8th day of May, 2026.

JILL NUSSBAUM

Jill Nussbaum

5540 Nathan Lane N #1

Plymouth, MN 55442

Clerk of Circuit Court

Minnehaha County Courthouse

425 N. Dakota Ave.

Sioux Falls, SD 57104

(605) 367-5900

Michael H. Paulson

Christopherson, Anderson, Paulson & Fideler, LLP

426 E. 8th St.

Sioux Falls, SD 57l03-7025

(605) 336-1030

Attorneys for Personal Representative

Published May 15, May 22 & May 29, 2026 at the approximate cost of $49.43, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, May 22, May 29 & June 5, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE PETITION OF:
DEAN MICHAEL DICKEY
FOR A CHANGE OF NAME TO:
MICHELLE DIANE DICKEY
FILE NO: 49CIV26-2007
NOTICE OF HEARING
FOR ADULT NAME CHANGE

NOTICE IS HEREBY GIVEN a Verified Petition for Adult Name Change has been filed by DEAN MICHAEL DICKEY the object and prayer of which is to change Petitioner’s name from DEAN MICHAEL DICKEY to MICHELLE DIANE DICKEY. on the 16th day of June, 2026, at the hour of 11:00 a.m. said verified petition will be heard by this Court before the Honorable Judge Mowery Presiding at the Court Room in the Minnehaha County Courthouse, City of Sioux Falls, Minnehaha County, South Dakota, or as soon thereafter as is convenient for the court. Anyone may come and appear at that time and place and show reasons, if any, why said name should not be changed as requested.

Dated this 30 day of April, 2026 at Minnehaha, South Dakota.

/s/Cathy Arant

Clerk of Court

Published May 15, May 22, May 29 & June 5, 2026 at the approximate cost of $58.73, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
DAVID J. GASPAR,
DECEASED.
PRO. 26-31
NOTICE TO CREDITORS

Notice is given that on February 22, 2026, Judy K. Gaspar, whose address is 1304 N. Vail Drive, Sioux Falls, South Dakota, was informally appointed as personal representative of the ESTATE OF DAVID J. GASPAR.

Creditors of decedent must file their claims within four months after the date of the first publication of this notice or their claims may be barred.

Claims may be filed with the personal representatives or may be filed with the Clerk, and a copy of the claim mailed to the personal representatives.

DATED this 1st day of May, 2026.

/s/ Judy K. Gaspar

JUDY K. GASPAR

Personal Representative

Gregory T. Brewers

Strange, Farrell, Johnson & Brewers, P.C.

4420 South Technology Drive

Sioux Falls, SD 57106

605-339-4500

Published May 15, May 22 & May 29, 2026 at the approximate cost of $43.56, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE GUARDIANSHIP AND CONSERVATORSHIP OF
JEROME D. LABORE,
A PERSON ALLEGED TO NEED PROTECTION.
49GDN26 – 000065
NOTICE OF HEARING ON PETITION
FOR APPOINTMENT OF
GUARDIAN AND CONSERVATOR

Notice is given that a Petition for Appointment of Guardian and Conservator has been filed and set for hearing within sixty days of its filing, in the courtroom at the Minnehaha County Courthouse, Sioux Falls, South Dakota, on Tuesday, June 30, 2026, at 11:00 o’clock a.m.

The petition alleges that Jerome D. LaBore’s ability to respond to people, events, and environments is impaired to such an extent that he lacks the capacity to meet the essential requirements for health, care, safety, habilitation or therapeutic needs and to manage property or financial affairs or to provide for himself without the assistance or protection of a guardian and conservator. A copy of the Petition and Evaluation Report shall be personally served upon Jerome D. LaBore not less than fourteen (14) days before the hearing.

If Jerome D. LaBore is determined to be a person in need of protection as alleged in the Petition, a guardian and conservator may be appointed on his behalf. If a guardian and conservator is appointed, the guardian and conservator may be given full or limited control of the care and custody of the person, as well as full or limited control of the property and financial affairs of Jerome D. LaBore and have the right to regulate certain or all activities.

The proposed guardian and conservator is required to attend except for good cause shown.

Jerome D. LaBore has the right to attend this hearing, to oppose the appointment of a Guardian and Conservator, to demand a jury trial, to present evidence, to compel the attendance of witnesses, and to confront and cross-examine all witnesses. He has the right to be represented by an attorney of his own choice or to an attorney appointed by the court upon request. Jerome D. LaBore has the right to request that the hearing be closed to the public.

Any individual or entity interested in these proceedings may apply for permission to participate at the hearing.

BY THE COURT:

/s/ Jeffrey C. Clapper

Judge of the Circuit Court

5/5/2026 4:24:23 PM

Published May 15, May 22 & May 29, 2026 at the approximate cost of $83.79, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, May 22, May 29 & June 5, 2026

COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
ALANNA ROSE MICHELLE CLARK
FOR A CHANGE OF NAME TO:
ALEXANDER JASPER LYNN
FILE NO: 49CIV26-2018
NOTICE OF HEARING
FOR ADULT NAME CHANGE

NOTICE IS HEREBY GIVEN that a Verified Petition for Adult Name Change has been filed by Alanna Rose Michelle Clark to change Petitioner’s name from Alanna Rose Michelle Clark to Alexander Jasper Lynn. The Petition will be heard on the 16th day of June, 2026, at 11:00 a.m. by the Honorable Judge Mandi Mowery, at the Minnehaha County Courthouse, in the City of Sioux Falls, South Dakota. Anyone may appear at that time and place and show reasons, if any, why Petitioner’s name should not be changed.

Dated this 1 day of May, 2026.

/s/Cathy Arant

Clerk of Court

Published May 15, May 22, May 29 & June 5, 2026 at the approximate cost of $52.15, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, May 22, May 29 & June 5, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
YUSEF AKIM SHARPE
FOR A CHANGE OF NAME TO:
YUSEF AKEEM MCMILLAN
FILE NO: 49CIV26-2112
NOTICE OF HEARING
FOR ADULT NAME CHANGE

NOTICE IS HEREBY GIVEN that a Verified Petition for Adult Name Change has been filed by Yusef Akim Sharpe to change Petitioner’s name from Yusef Akim Sharpe to Yusef Akeem McMillan. The Petition will be heard on the 16th day of June, 2026, at 11:00 a.m. by the Honorable Judge Mowery, at the Minnehaha County Courthouse, in the City of Sioux Falls, South Dakota. Anyone may appear at that time and place and show reasons, if any, why Petitioner’s name should not be changed.

Dated this 6 day of May, 2026.

/s/Mandi Mowery

Circuit Court Judge

Published May 15, May 22, May 29 & June 5, 2026 at the approximate cost of $49.95, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8, May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF LINCOLN
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
BART BROST AND REBECCA BROST
PLAINTIFFS,
VS.
JUDITH A. HAUGO; AND
ALL PERSONS UNKNOWN CLAIMING ANY RIGHT OR
INTEREST TO THE REAL PROPERTY DESCRIBED IN THE PLAINTIFFS’ COMPLAINT ADVERSE TO THE PLAINTIFFS’
CLAIM OF OWNERSHIP OR ANY CLOUD ON PLAINTIFFS’
CLAIM OF TITLE,
DEFENDANTS.
41CIV25-001059
AMENDED SUMMONS
AND
NOTICE OF NO PERSONAL CLAIM FOR PUBLICTION

You are hereby summoned and required to serve upon Hagen, Wilka & Archer, LLP, attorneys for the Plaintiff, whose address is 600 South Main Avenue, Suite 102, PO Box 964, Sioux Falls, South Dakota 57101-0964, an Answer to the Amended Complaint, which was filed on March 9, 2026 at the Clerk of Courts, Lincoln County Courthouse, South Dakota. You must serve your Answer within thirty (30) days after the service of this Amended Summons upon you, exclusive of the day of service, and if you fail to answer within said time, judgment by default may be rendered against you for the relief requested in the Amended Complaint.

NOTICE OF NO PERSONAL CLAIM

TO THE ABOVE-NAMED DEFENDANT: YOU WILL TAKE NOTICE that the above entitled action is brought for the purpose of determining adverse claims and for quieting title to certain real property situated in Lincoln County, South Dakota, described as follows:

EGGE TRACT NO. 2 IN THE WEST HALF OF THE SOUTHWEST QUARTER (W1/2SW1/4) OF SECTION 11, TOWNSHIP 100, RANGE 49 WEST OF THE 5TH P.M., LINCOLN COUNTY, SOUTH DAKOTA.

YOU ARE FURTHER NOTIFIED THAT NO PERSONAL CLAIM is made in said action against the Defendant to whom this notice is directed. Therefore, in accordance with SDCL § 15-9-6, no costs will be taxed or money judgments taken against you unless you defend this action.

Dated this 4th day of May, 2026 at Sioux Falls, South Dakota.

HAGEN, WILKA & ARCHER, LLP

/s/ Sara E. Schroeder

Sara E. Schroeder

600 S. Main Avenue, Suite 102

P.O. Box 964

Sioux Falls, SD 57101-0964

Telephone: (605) 334-0005

Facsimile: (605) 334-4814

E-Mail: Sara@hwalaw.com

Attorneys for Plaintiffs

Published May 8, May 15, May 22 & May 29, 2026 at the approximate cost of $111.33, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8, May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
NORMA TANISHA ZAVALA CUELLAR,
PLAINTIFF,
VS.
MILTHON FRANSICO MONTES GARCIA,
DEFENDENT.
49CIV25-
SUMMONS

TO MIL THON FRANSICO MONTES GARCIA, THE ABOVE-NAMED DEFENDANT:

YOU ARE HEREBY SUMMONED and required to answer the Verified Complaint for Sole Legal and Physical Custody and Petition for Name Change of Minor Child, a copy of which is herewith served upon you and is filed with the above-named Court, and to serve a copy of your Answer on Plaintifrs attorney, Casey Eekhoff, at the address below, within thirty (30) days from the date of the service of this Summons upon you, exclusive of the day of such service.

IF YOU FAIL TO DO SO, judgment by default may be rendered against you for the relief demanded in the Complaint sixty (60} days from the day of service of this Summons and Verified Complaint for Sole Legal and Physical Custody, and Name Change of Minor Child, not counting the day of service.

NOTICE

South Dakota law provides that upon the filing and service of the Summons and Verified Complaint for Sole Legal and Physical Custody and Petition for Name Change of Minor Child on the Defendant, an Initial Custody Order shall be in effect against both parties until the final decree is entered, the Verified Complaint for Sole Legal and Physical Custody and Petition for Name Change of Minor Child, is dismissed or until further order of the court. Either party may apply to the Court for further temporary orders or modification or revocation of this Order.

INITIAL CUSTODY ORDER

Pursuant to SDCL § 25-4A-11 et seq., upon service of this Summons the attached South Dakota Parenting Guidelines (Form UJS-302) become an order of this court. Any minor children shall remain in the custody of the parent who has been the primary caregiver for the minor children for the majority of time in the twelve months preceding the filing of the Summons and Verified Complaint for Sole Legal and Physical Custody and Petition for Name Change of Minor Child, which is the Plaintiff in this case unless the parties otherwise agree. The guidelines are subject to any provision established by a South Dakota state court in the following: a temporary or permanent protection order, an order arising out of an abuse or neglect proceeding, a bond condition arising out of a criminal case, and an order in any other proceeding affecting child custody or support.

The attached guidelines apply and shall continue in effect unless the parties agree or the court otheiwise orders. Imposition of these standard guidelines creates no presumption as to who may be awarded custody at any hearing. An agreement by the parties for visitation other than the standard guidelines must be in writing, signed by both parties, and filed with the court. The agreed plan shall be approved by court order and replace the standard guidelines, or any plan previously filed.

If either party object to the implementation of the South Dakota Parenting Guidelines (Form UJS-302) as the initial custody arrangement, the objecting party shall file an objection with the Clerk of Court. The court shall order a hearing which shall be held not later than 30 days after the date of objection. The court shall then issue its temporary custody and visitation order after considering the best interest of the child(ren) consistent with the provisions of SDCL § 25-4-45.

Dated this 28th day of August, 2025.

Eekhoff Law, Prof. LLC

/s/ Casey L. Eekhoff

Casey L. Eekhoff

300 N. Dakota Avenue, Suite 215

Sioux Falls, SD 57104

(605)368-1455

casey@eekhofflaw.com

Attorney for Plaintiff

Filed: 9/2/2025 3:48 PM CST Minnehaha County, South Dakota 49CIV25-003960

Published May 8, May 15, May 22 & May 29, 2026 at the approximate cost of $165.06, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8, May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
DONNA JEAN HIGHTREE
FOR A CHANGE OF NAME TO:
DONNA JEAN JONES
FILE NO: 49CIV26-2038
NOTICE OF HEARING
FOR ADULT NAME CHANGE

NOTICE IS HEREBY GIVEN that a Verified Petition for Adult Name Change has been filed by Donna Jean Hightree, to change Petitioner’s name from Donna Jean Hightree to Donna Jean Jones. The Petition will be heard on the 16 day of June, 2026, at 11:00 a.m. by the Honorable Judge Mowery, at the Minnehaha County Courthouse, in the City of Sioux Falls, South Dakota. Anyone may appear at that time and place and show reasons, if any, why Petitioner’s name should not be changed.

Dated this 1 day of May, 2026.

/s/ Cathy Arant

Clerk of Court

Published May 8, May 15, May 22 & May 29, 2026 at the approximate cost of $48.84, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8, May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
JIAXIN WEN
FOR A CHANGE OF NAME TO:
JIAXIN NICOLE WEN
FILE NO: 49CIV26-2068
NOTICE OF HEARING
FOR ADULT NAME CHANGE

NOTICE IS HEREBY GIVEN that a Verified Petition for Adult Name Change has been filed by Jiaxin Wen, to change Petitioner’s name from Jiaxin Wen to Jiaxin Nicole Wen. The Petition will be heard on the 16 day of June, 2026, at 11:00 a.m. by the Honorable Judge Mandi Mowery, at the Minnehaha County Courthouse, in the City of Sioux Falls, South Dakota. Anyone may appear at that time and place and show reasons, if any, why Petitioner’s name should not be changed.

Dated this 5 day of May, 2026.

/s/ Cathy Arant

Clerk of Court

Published May 8, May 15, May 22 & May 29, 2026 at the approximate cost of $47.77, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8, May 15, May 22 & May 29, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
KRISTINA LILA MCSWEENEY
FOR A CHANGE OF NAME TO:
KRISTINA LILA KLEIN
FILE NO: 49CIV26-2013
NOTICE OF HEARING
FOR ADULT NAME CHANGE

NOTICE IS HEREBY GIVEN that a Verified Petition for Adult Name Change has been filed by Kristina Lila McSweeney, to change Petitioner’s name from Kristina Lila McSweeney to Kristina Lila Klein. The Petition will be heard on the 16 day of June, 2026, at 11:00 a.m. by the Honorable Judge Mowery, at the Minnehaha County Courthouse, in the City of Sioux Falls, South Dakota. Anyone may appear at that time and place and show reasons, if any, why Petitioner’s name should not be changed.

Dated this 30 day of April, 2026.

/s/ Cathy Arant

Clerk of Court

Published May 8, May 15, May 22 & May 29, 2026 at the approximate cost of $52.15, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 1, May 8 & May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
JACKIE LEE HARMS,
DECEASED.
49PRO. 26-000097

Notice to Creditors and Notice of Informal Probate and Appointment of Personal Representative in Intestacy

NOTICE is hereby given that on the 28th day of April, 2026, Bonnie Guhlke, of 820 N. Fairfax Avenue, Sioux Falls, South Dakota 57103, was appointed as Personal Representative of the Estate of Jackie Lee Harms, deceased.

Creditors of decedent must file their claims within four months after the date of the first publication of this notice or their claims may be barred.

Claims may be filed with the Personal Representative or may be filed with the Clerk of Court, and a copy of the claim mailed to the Personal Representative.

Dated this 28th day of April, 2026.

/s/ Bonnie Guhlke

Bonnie Guhlke

820 N. Fairfax Ave.

Sioux Falls, SD 57103

Karla Kalb

Minnehaha County Clerk of Courts

425 North Dakota Avenue

Sioux Falls, SD 57104

605-782-3004

Michael J. McGill

Attorney for Estate

P.O. Box 32

Beresford, SD 57004

605-763-2057

Published May 1, May 8 & May 15, 2026 at the approximate cost of $53.62, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 1, May 8 & May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
CLARICE J. INGLEBRET,
DECEASED.
PRO. 26-93
NOTICE TO CREDITORS

Notice is given that on April 24, 2026, Tim Houska, whose address is 3900 S. Pillsberry Ave., Sioux Falls, SD 57103, was appointed as personal representative of the estate of Clarice J. Inglebret.

Creditors of decedent must file their claims within four months after the date of the first publication of this notice or their claims may be barred.

Claims may be filed with the personal representative or may be filed with the Clerk, and a copy of the claim mailed to the personal representative.

Dated this 28 day of April, 2026.

/s/ Tim Houska

Tim Houska

3900 S. Pillsberry Ave.

Sioux Falls, SD 57103

Clerk of Circuit Court

Minnehaha County Courthouse

425 N. Dakota Ave.

Sioux Falls, SD 57104

(605) 367-5900

Michael H. Paulson

Christopherson, Anderson,

Paulson & Fideler, LLP

426 E. 8th St.

Sioux Falls, SD 57l03-7025

(605) 336-1030

Attorneys for Personal Representative

Published May 1, May 8 & May 15, 2026 at the approximate cost of $49.43, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: Apr. 24, May 1, May 8 & May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE NAME CHANGE OF
JEANETTE MARIE RACKL.
49CIV26-001451
ORDER AND NOTICE FOR HEARING

TO INTERESTED PERSONS:

Please take notice that a Petition for Name Change of Jeanette Marie Rackl has been filed, requesting that the legal name of the Petitioner herein, “Jeanette Marie Rackl” be changed to “Jeanette Marie Wegner.”

IT IS HEREBY ORDERED that a hearing will be had on said Petition on June 15, 2026, at 1:30 p.m., or as soon thereafter as counsel may be heard, at the Minnehaha County Courthouse, Sioux Falls, South Dakota.

BY THE COURT

/s/ Jennifer D. Mammenga

Honorable Jennifer D. Mammenga

Circuit Court Judge

Published Apr. 24, May 1, May 8 & May 15, 2026 at the approximate cost of $47.77, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 8 & May 15, 2026

IN THE STATE OF SOUTH DAKOTA,
COUNTY OF MINNEHAHA
IN CIRCUIT COURT,
SECOND JUDICIAL CIRCUIT COURT
WILMINGTON SAVINGS FUND SOCIETY, FSB, NOT IN ITS INDIVIDUAL CAPACITY, BUT SOLELY AS OWNER TRUSTEE OF CSMC 2019-RPL11 TRUST,
PLAINTIFF,
V.
JACQUELINE MORGAN AND JERRY E. MORGAN A/K/A JERRY MORGAN A/K/A GERALD MORGAN AND SIOUX EMPIRE FEDERAL CREDIT UNION AND A.A.A. COLLECTIONS, INC. AND ACCOUNTS MANAGEMENT, INC. AND HEIRS & DEVISEES OF THE ESTATE OF JERRY E. MORGAN, AND ANY PERSON IN POSSESSION,
DEFENDANTS.
NOTICE OF REAL ESTATE SALE ON FORECLOSURE
CIVIL NUMBER: 49CIV24-004602

A Non-Monetary Judgment of Foreclosure was entered in favor of Plaintiff and against Defendants, which judgment was filed with the Clerk of Courts of Minnehaha County, South Dakota, on March 30, 2026, in the amount of $108,565.62, for the foreclosure of a real estate mortgage.

Notice is hereby given pursuant to said judgment that the real property described in

the Real Estate Mortgage dated May 5, 2008, and recorded in the office of the Register of Deeds of Minnehaha County, South Dakota, on May 15, 2008, in Book 1598 of Mtgs, at Page 334, as Instrument Number R814514 which Jacqueline Morgan and Jerry E. Morgan, mortgagor, executed and delivered to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Wachovia Mortgage, FSB, its successors and assigns, mortgagee, for the property located at 7405 West 12th Street, Sioux Falls, SD 57106, and legally described as:

The West Half (W 1/2) of Tract 2 In the Northwest Quarter of the Northeast Quarter (NW 1/4 NE 1/4) of Section 22, Township 101 North, Range 50 West of the 5th P.M., Minnehaha County, South Dakota, according to the recorded plat thereof, except Lot H-1 contained therein

in order to realize the amount of the above-referenced judgment, plus interest accruing thereafter on said amount, together with the costs and expenses of sale, will be sold subject to redemption as provided by law as one parcel of land at public auction, subject to easements and restrictions of record, to the highest bidder for cash under the direction of the Minnehaha County Sheriff, at the Law Enforcement Center located at 320 West 4th Street, Sioux Falls, SD 57104, on June 3, 2026 at 11:00 AM.

Dated this 23rd day of April, 2026

SHERIFF OF MINNEHAHA COUNTY

By: Michael C. Brenden #548

Name: Michael Brenden

Deputy Sheriff

Halliday, Watkins & Mann, P.C.

By/s/Jason Tingle

Jason Tingle

Attorneys for Plaintiff

376 East 400 South, Suite 300

Salt Lake City, UT 84111

Tel: 801-355-2886

Email: jtingle@hwmlawfirm.com

Published twice on May 8 & May 15, 2026, at the approximate cost of $71.13, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
Q P, Q P,
ALLEGED ABUSED/NEGLECTED CHILDREN
AND CONCERNING
YA’VONDA RENEE ESTIS
QUERRETERRION MARTEZ PAYNE SR
RESPONDENTS
JUV26-000383
SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: YA’VONDA RENEE ESTIS

QUERRETERRION MARTEZ PAYNE SR

AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on June 2, 2026, at 9:00 AM to answer the Petition of CARRIE MEES, now on file with the Clerk of said Court, alleging the above named Children to be an abused/neglected Children and praying that said Children be taken from you and that a guardian be appointed with authority to consent to the adoption of said Children. You must appear at the time and place set forth above to show cause, if any you have, why said Children should not be found abused/neglected and the prayer of said Petition granted or said Children otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Children have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 9th day of April, 2026.

KARLA KALB, Clerk

BY: /s/ Alyssa King

Deputy

Published once on May 15, 2026, at the approximate cost of $25.12, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
A S,
ALLEGED ABUSED/NEGLECTED CHILD
AND CONCERNING
MELLISSA LYNN SHEPARD
UNKNOWN FATHER
RESPONDENTS
JUV26-000001
AMENDED SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: MELLISSA LYNN SHEPARD, UNKNOWN FATHER, Matthew Thomas

AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on September 3, 2026, at 9:00 AM to answer the Petition of CARRIE MEES, now on file with the Clerk of said Court, alleging the above named Child to be an abused/neglected Child and praying that said Child be taken from you and that a guardian be appointed with authority to consent to the adoption of said Child. You must appear at the time and place set forth above to show cause, if any you have, why said Child should not be found abused/neglected and the prayer of said Petition granted or said Child otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Child have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 5th day of May, 2026.

KARLA KALB, Clerk

BY: /s/ Alyssa King

Deputy

Published once on May 15, 2026, at the approximate cost of $24.15, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
D H, G H, M H, A T,
ALLEGED ABUSED/NEGLECTED CHILDREN
AND CONCERNING
ELDOTH LOUISE LECLAIRE
KEVIN FOSTER HUBBELING
MICHAEL ALLEN LECLAIRE
CHRISTOPHER WAYNE THUNDERHORSE
RESPONDENTS
JUV25-001609
AMENDED SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: ELDOTH LOUISE LECLAIRE

KEVIN FOSTER HUBBELING

MICHAEL ALLEN LECLAIRE

CHRISTOPHER WAYNE THUNDERHORSE

AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on September 9, 2026, at 9:00 AM to answer the Petition of Carrie Mees/Brianna Palomaki/Lyndee Kamrath, now on file with the Clerk of said Court, alleging the above named Children to be an abused/neglected Children and praying that said Children be taken from you and that a guardian be appointed with authority to consent to the adoption of said Children. You must appear at the time and place set forth above to show cause, if any you have, why said Children should not be found abused/neglected and the prayer of said Petition granted or said Children otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Children have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 5th day of May, 2026.

KARLA KALB, Clerk

BY: /s/ Alyssa King

Deputy

Published once on May 15, 2026, at the approximate cost of $27.05, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
K S,
ALLEGED ABUSED/NEGLECTED CHILD
AND CONCERNING
TIARA SKYE SAILS
UNKNOWN FATHER
RESPONDENTS
JUV24-001425
6TH AMENDED SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: TIARA SKYE SAILS, UNKNOWN FATHER, Roberto Diaz AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on June 16, 2026, at 10:00 AM to answer the Petition of BRIANNA PALOMAKI, now on file with the Clerk of said Court, alleging the above named Child to be an abused/neglected Child and praying that said Child be taken from you and that a guardian be appointed with authority to consent to the adoption of said Child. You must appear at the time and place set forth above to show cause, if any you have, why said Child should not be found abused/neglected and the prayer of said Petition granted or said Child otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Child have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 11th day of May, 2026.

KARLA KALB, Clerk

BY: /s/ Alyssa King

Deputy

Published once on May 15, 2026, at the approximate cost of $23.83, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
E A, D Z,
ALLEGED ABUSED/NEGLECTED CHILDREN
AND CONCERNING
AMIYAH TELISA ANN ZIELIEKE
DAWIT TEKLAY ACHO
UNKNOWN FATHER
RESPONDENTS
JUV26-000203
AMENDED SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: AMIYAH TELISA ANN ZIELIEKE, DAWIT TEKLAY ACHO, UNKNOWN FATHER, Devon Collymore AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on June 9, 2026, at 9:00 AM to answer the Petition of BRIANNA PALOMAKI, now on file with the Clerk of said Court, alleging the above named Children to be an abused/neglected Children and praying that said Children be taken from you and that a guardian be appointed with authority to consent to the adoption of said Children. You must appear at the time and place set forth above to show cause, if any you have, why said Children should not be found abused/neglected and the prayer of said Petition granted or said Children otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Children have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 12th day of May, 2026.

KARLA KALB, Clerk

BY: /s/ Brenda Jarrott

Deputy

Published once on May 15, 2026, at the approximate cost of $25.44, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
N T,
ALLEGED ABUSED/NEGLECTED CHILD
AND CONCERNING
BRIANE FAITH TURNER
NORMAN BROWN
RESPONDENTS
JUV25-000977
2ND AMENDED SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: BRIANE FAITH TURNER

NORMAN BROWN

AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on June 29, 2026, at 11:00 AM to answer the Petition of BRIANNA PALOMAKI, now on file with the Clerk of said Court, alleging the above named Child to be an abused/neglected Child and praying that said Child be taken from you and that a guardian be appointed with authority to consent to the adoption of said Child. You must appear at the time and place set forth above to show cause, if any you have, why said Child should not be found abused/neglected and the prayer of said Petition granted or said Child otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Child have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 13th day of May, 2026.

KARLA KALB, Clerk

BY: /s/ Hannah Ludlow

Deputy

Published once on May 15, 2026, at the approximate cost of $23.83, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
H B, H F JR, H F, L F, E P, C P, M P,
ALLEGED ABUSED/NEGLECTED CHILDREN
AND CONCERNING
AMANDA BROOKE PROVENCIAL
UNKNOWN FATHERS
HILARIO JACOB FLORES, SR
JARED VINCENT PHERNETTON
RESPONDENTS
JUV26-000076
AMENDED SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: AMANDA BROOKE PROVENCIAL, UNKNOWN FATHERS, HILARIO JACOB FLORES, SR, JARED VINCENT PHERNETTON AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on September 16, 2026, at 9:00 AM to answer the Petition of CARRIE MEES, now on file with the Clerk of said Court, alleging the above named Children to be an abused/neglected Children and praying that said Children be taken from you and that a guardian be appointed with authority to consent to the adoption of said Children. You must appear at the time and place set forth above to show cause, if any you have, why said Children should not be found abused/neglected and the prayer of said Petition granted or said Children otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Children have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 13th day of May, 2026.

KARLA KALB, Clerk

BY: /s/ Hannah Ludlow

Deputy

Published once on May 15, 2026, at the approximate cost of $26.41, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: May 15, 2026

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
THE PEOPLE OF THE STATE OF SOUTH DAKOTA
EX REL, SOUTH DAKOTA DEPARTMENT OF SOCIAL SERVICES, IN THE INTEREST OF,
C S,
ALLEGED ABUSED/NEGLECTED CHILD
AND CONCERNING
SAMANTHA LYNN SILK
UNKNOWN FATHER
RESPONDENTS
JUV26-000108
AMENDED SUMMONS
(ALLEGED ABUSED OR NEGLECTED CHILD)

TO: SAMANTHA LYNN SILK, UNKNOWN FATHER, Braulio Garcia

AND ALL WHOM IT MAY CONCERN

You are hereby summoned to appear before the above-named Court in its courtroom at the Minnehaha County Courthouse, 425 North Dakota Avenue, Sioux Falls, South Dakota, on September 16, 2026, at 9:00 AM to answer the Petition of CARRIE MEES, now on file with the Clerk of said Court, alleging the above named Child to be an abused/neglected Child and praying that said Child be taken from you and that a guardian be appointed with authority to consent to the adoption of said Child. You must appear at the time and place set forth above to show cause, if any you have, why said Child should not be found abused/neglected and the prayer of said Petition granted or said Child otherwise dealt with. Failure to appear is an admission to the allegation(s) contained in the Petition. You are further notified that the termination of parental rights is a possible remedy of these proceedings and that you and the above-named Child have the right to have an attorney present at all stages of the proceedings.

Dated at Sioux Falls, Minnehaha County, South Dakota, this 13th day of May, 2026.

KARLA KALB, Clerk

BY: /s/ Hannah Ludlow

Deputy

Published once on May 15, 2026, at the approximate cost of $24.15, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

Discussion about this post

Ready for more?

Legals & Public Notices: May 15, 2026

City of Sioux Falls, Sioux Falls School District, City of Baltic, Sheriff's Sales, Foreclosure Sales, Name Changes, Notices to Creditors, Summons

CITY OF SIOUX FALLS

BID REQUEST NO. 26-1002NOTICE TO BIDDERS

BID REQUEST NO. 26-1077NOTICE TO BIDDERS

BID REQUEST NO.: 26-1090NOTICE TO BIDDERS

BID REQUEST NO.26-0074NOTICE TO BIDDERS

BID REQUEST NO. 26-1088NOTICE TO BIDDERS

BID REQUEST NO.: 26-1087NOTICE TO BIDDERS

BID REQUEST NO.: 26-1063NOTICE TO BIDDERS

BID REQUEST NO. 26-1042NOTICE TO BIDDERS

BID REQUEST NO. 26-0073NOTICE TO BIDDERS

BID REQUEST NO. 26-0072NOTICE TO BIDDERS

BID REQUEST NO. 26-0065NOTICE TO BIDDERS

BID REQUEST NO. 26-1089NOTICE TO BIDDERS

NOTICE OF HEARING—VACATE PUBLIC RIGHT-OF-WAY

NOTICE OF HEARING—VACATE PUBLIC RIGHT-OF-WAY

ORDINANCE NO. 35-26

MINUTES

SIOUX FALLS SCHOOL DISTRICT

ADVERTISEMENT FOR BIDS

ADVERTISEMENT FOR REQUEST FOR PROPOSALS

ADVERTISEMENT FOR BIDS

SCHOOL BOARD MEETING

SCHOOL BOARD MEETING

CITY OF BALTIC

NOTICE OF PUBLIC HEARING

NOTICE OF VACANCY MUNICIPALITY OF BALTIC, SOUTH DAKOTA

LINCOLN COUNTY

NOTICE OF PUBLIC HEARING

NOTICE OF SALE OF COUNTY SURPLUS PROPERTY

LINCOLN COUNTY BOARD OF COMMISSIONMEETING MINUTES APRIL 28, 2026

APRIL 21, 2026COUNTY BOARD OF EQUALIZATION

PUBLIC NOTICE

FORM 6SOUTH DAKOTA LOTTERY COMMISSIONNOTICE OF PUBLIC HEARING TO ADOPT RULES

NOTICE OF SALE

INVITATION TO BID

COURTS

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHA:SS IN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE ESTATE OFMERLE NUSSBAUM,DECEASED.49PRO26-000104NOTICE TO CREDITORS

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHAIN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE PETITION OF:DEAN MICHAEL DICKEYFOR A CHANGE OF NAME TO:MICHELLE DIANE DICKEYFILE NO: 49CIV26-2007NOTICE OF HEARINGFOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHA:SS IN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE ESTATE OFDAVID J. GASPAR,DECEASED.PRO. 26-31NOTICE TO CREDITORS

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHA:SS IN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE GUARDIANSHIP AND CONSERVATORSHIP OFJEROME D. LABORE,A PERSON ALLEGED TO NEED PROTECTION.49GDN26 – 000065NOTICE OF HEARING ON PETITIONFOR APPOINTMENT OFGUARDIAN AND CONSERVATOR

COUNTY OF MINNEHAHAIN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE PETITION OF:ALANNA ROSE MICHELLE CLARKFOR A CHANGE OF NAME TO:ALEXANDER JASPER LYNNFILE NO: 49CIV26-2018NOTICE OF HEARINGFOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHAIN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE PETITION OF:YUSEF AKIM SHARPEFOR A CHANGE OF NAME TO:YUSEF AKEEM MCMILLANFILE NO: 49CIV26-2112NOTICE OF HEARINGFOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHA:SS IN CIRCUIT COURTSECOND JUDICIAL CIRCUITNORMA TANISHA ZAVALA CUELLAR,PLAINTIFF,VS.MILTHON FRANSICO MONTES GARCIA,DEFENDENT.49CIV25-SUMMONS

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHAIN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE PETITION OF:DONNA JEAN HIGHTREEFOR A CHANGE OF NAME TO:DONNA JEAN JONESFILE NO: 49CIV26-2038NOTICE OF HEARINGFOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHAIN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE PETITION OF:JIAXIN WENFOR A CHANGE OF NAME TO:JIAXIN NICOLE WENFILE NO: 49CIV26-2068NOTICE OF HEARINGFOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHAIN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE PETITION OF:KRISTINA LILA MCSWEENEYFOR A CHANGE OF NAME TO:KRISTINA LILA KLEINFILE NO: 49CIV26-2013NOTICE OF HEARINGFOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHA:SS IN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE ESTATE OFJACKIE LEE HARMS,DECEASED.49PRO. 26-000097

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHA:SS IN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE ESTATE OFCLARICE J. INGLEBRET,DECEASED.PRO. 26-93NOTICE TO CREDITORS

STATE OF SOUTH DAKOTACOUNTY OF MINNEHAHA:SS IN CIRCUIT COURTSECOND JUDICIAL CIRCUITIN THE MATTER OF THE NAME CHANGE OFJEANETTE MARIE RACKL.49CIV26-001451ORDER AND NOTICE FOR HEARING

Discussion about this post

Ready for more?

BID REQUEST NO. 26-1002
NOTICE TO BIDDERS

BID REQUEST NO. 26-1077
NOTICE TO BIDDERS

BID REQUEST NO.: 26-1090
NOTICE TO BIDDERS

BID REQUEST NO.26-0074
NOTICE TO BIDDERS

BID REQUEST NO. 26-1088
NOTICE TO BIDDERS

BID REQUEST NO.: 26-1087
NOTICE TO BIDDERS

BID REQUEST NO.: 26-1063
NOTICE TO BIDDERS

BID REQUEST NO. 26-1042
NOTICE TO BIDDERS

BID REQUEST NO. 26-0073
NOTICE TO BIDDERS

BID REQUEST NO. 26-0072
NOTICE TO BIDDERS

BID REQUEST NO. 26-0065
NOTICE TO BIDDERS

BID REQUEST NO. 26-1089
NOTICE TO BIDDERS

NOTICE OF HEARING—
VACATE PUBLIC RIGHT-OF-WAY

NOTICE OF HEARING—
VACATE PUBLIC RIGHT-OF-WAY

NOTICE OF VACANCY
MUNICIPALITY OF BALTIC, SOUTH DAKOTA

NOTICE OF SALE
OF COUNTY SURPLUS PROPERTY

LINCOLN COUNTY BOARD OF COMMISSION
MEETING MINUTES APRIL 28, 2026

APRIL 21, 2026
COUNTY BOARD OF EQUALIZATION

FORM 6
SOUTH DAKOTA LOTTERY COMMISSION
NOTICE OF PUBLIC HEARING TO ADOPT RULES

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
MERLE NUSSBAUM,
DECEASED.
49PRO26-000104
NOTICE TO CREDITORS

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE PETITION OF:
DEAN MICHAEL DICKEY
FOR A CHANGE OF NAME TO:
MICHELLE DIANE DICKEY
FILE NO: 49CIV26-2007
NOTICE OF HEARING
FOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
DAVID J. GASPAR,
DECEASED.
PRO. 26-31
NOTICE TO CREDITORS

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE GUARDIANSHIP AND CONSERVATORSHIP OF
JEROME D. LABORE,
A PERSON ALLEGED TO NEED PROTECTION.
49GDN26 – 000065
NOTICE OF HEARING ON PETITION
FOR APPOINTMENT OF
GUARDIAN AND CONSERVATOR

COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
ALANNA ROSE MICHELLE CLARK
FOR A CHANGE OF NAME TO:
ALEXANDER JASPER LYNN
FILE NO: 49CIV26-2018
NOTICE OF HEARING
FOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
YUSEF AKIM SHARPE
FOR A CHANGE OF NAME TO:
YUSEF AKEEM MCMILLAN
FILE NO: 49CIV26-2112
NOTICE OF HEARING
FOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
NORMA TANISHA ZAVALA CUELLAR,
PLAINTIFF,
VS.
MILTHON FRANSICO MONTES GARCIA,
DEFENDENT.
49CIV25-
SUMMONS

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
DONNA JEAN HIGHTREE
FOR A CHANGE OF NAME TO:
DONNA JEAN JONES
FILE NO: 49CIV26-2038
NOTICE OF HEARING
FOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
JIAXIN WEN
FOR A CHANGE OF NAME TO:
JIAXIN NICOLE WEN
FILE NO: 49CIV26-2068
NOTICE OF HEARING
FOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE
PETITION OF:
KRISTINA LILA MCSWEENEY
FOR A CHANGE OF NAME TO:
KRISTINA LILA KLEIN
FILE NO: 49CIV26-2013
NOTICE OF HEARING
FOR ADULT NAME CHANGE

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
JACKIE LEE HARMS,
DECEASED.
49PRO. 26-000097

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
CLARICE J. INGLEBRET,
DECEASED.
PRO. 26-93
NOTICE TO CREDITORS

STATE OF SOUTH DAKOTA
COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT
SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE NAME CHANGE OF
JEANETTE MARIE RACKL.
49CIV26-001451
ORDER AND NOTICE FOR HEARING