Legals & Public Notices: Oct. 18, 2024

City of Sioux Falls, Bid Notices, Name Changes, Summons, Public Notices, Pardon Applications, Notices to Creditors, Notice of Sale

CITY OF SIOUX FALLS

PUBLISH: Oct. 11 & Oct. 18, 2024

BID REQUEST NO. 24-0114
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for Asbestos Removal and Disposal.

To participate, you must be registered as a vendor in Bonfire. Register at siouxfalls.bonfirehub.com by selecting “Register” next to the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through Bonfire and will be received by Bonfire not later than 2 p.m., Central time, October 24, 2024. Immediately thereafter, the bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

There will be a pre-bid meeting held on October 15, 2024, at 3 p.m. at 1000 E. Chambers St., Sioux Falls, SD for interested bidders.

It is the vendor’s responsibility to check the Bonfire website for any changes or updates to the Invitation for Bid, which will be in the form of an addendum posted to the Bonfire website.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on Oct. 11 & Oct. 18, 2024, at the approximate cost of $33.01, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLISH: Oct. 11 & Oct. 18, 2024

BID REQUEST NO. 25-0007
REQUEST FOR PROPOSAL

The City of Sioux Falls, SD, requests competitive sealed proposals for Vending Services.

To participate, proposers must be registered as a vendor in Bonfire. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” under the login tab. After you have registered, navigate to the Open Public Opportunities tab to view the solicitation. Proposals will be electronically submitted through Bonfire and will be received by Bonfire not later than 2 p.m., Central standard time, October 31, 2024. Proposals will be publicly opened but not read at 3 p.m., Central standard time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

It is the vendor’s responsibility to check the Bonfire website for any changes or updates to the Competitive Sealed Proposal, which will be in the form of an addendum posted to the solicitation in Bonfire.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all bids or proposals, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on Oct. 11 & Oct. 18, 2024, at the approximate cost of $30.74, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 11 & Oct. 18, 2024

BID REQUEST NO. 25-0004
REQUEST FOR PROPOSALS

The City of Sioux Falls, SD, requests competitive sealed proposals to complete Preliminary Design and State Revolving Fund (SRF) Facility Plan Preparation for the City of Sioux Falls Water Reclamation Primary Clarifier Expansion Project.

To participate, you must be registered as a vendor in Bonfire. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” under the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this Request for Proposal. Proposals will be electronically submitted through Bonfire and will be received by Bonfire no later than 2 p.m., Central time, November 14, 2024. Immediately thereafter, the bids will be publicly opened but not read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

It is the vendor’s responsibility to check the Bonfire website for any changes or updates to the request for proposal, which will be in the form of an addendum posted to the Bonfire website.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all proposals, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on Oct. 11 & Oct. 18, 2024, at the approximate cost of $33.58, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 11 & Oct. 18, 2024

BID REQUEST NO. 25-0009
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for the Removal of Ash Trees in the City Right-of-Way.

To participate, you must be registered as a vendor in Bonfire. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” under the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through Bonfire and will be received by Bonfire not later than 2 p.m., Central time, October 31, 2024. Immediately thereafter, the bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/purchasing.

There will be a pre-bid meeting held on Tuesday, October 22, 2024, at 11 a.m. at the City Center, Room 110, for interested bidders. A virtual option is available upon request.

It is the vendor’s responsibility to check the Bonfire website for any changes or updates to the Invitation for Bid, which will be in the form of an addendum posted to the Bonfire website.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the solicitation.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Published twice on Oct. 11 & Oct. 18, 2024, at the approximate cost of $34.14, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18 & Oct. 25, 2024

BID REQUEST NO. 24-1059
NOTICE TO BIDDERS

The City of Sioux Falls, SD requests formal bids for: Law Enforcement Center Lighting Retrofit Rebid.

To participate, you must be registered as a vendor in Bonfire. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” under the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through Bonfire and will be received by Bonfire not later than 2 p.m., Central time, November 7, 2024. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at https://www.siouxfalls.gov/business-permits/bids- procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the Bonfire website for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the Bonfire website.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make Award(s) as deemed to be in the best interest of Sioux Falls, SD.

Federal financial assistance will be used to fund all or a portion of the contract. The contractor will comply with all applicable Federal laws, regulations, executive orders, Federal policies, procedures, and directives including, but not limited to 2 CFR

§§200.318-200.327.

Bidders for this work will be required to comply with the President’s Executive Order Nos. 11246 as amended, 11518 and 11625 as amended. The requirements for bidders and contractors under these orders are explained in the specifications.

The City of Sioux Falls has adopted a Disadvantaged Business Enterprise Plan. This Plan expresses the commitment of the City of Sioux Falls that disadvantaged business enterprises have the maximum opportunity to compete for and perform federally assisted contracts and subcontracts.

The City of Sioux Falls has available the latest Disadvantaged Business Enterprise directory in the Finance Department to facilitate identifying those certified disadvantaged business enterprises within the state of South Dakota.

Bidders on this work will be required to comply with Title 40 CFR 33 and Executive Order 12138. The requirements for bidders and contractors under this regulation which concerns utilization of Disadvantaged/Minority Business Enterprises (DBE/MBE) and Women’s Business Enterprises (WBE) are explained in the specifications. The DBE/MBE and WBE goals for participation in this contract in terms of percentage of contract value are as follows: MBE 1.0 percent; WBE 4.0 percent.

Only firms certified at the time of the letting and included on the DBE Directory at dot.sd.gov, will count toward DBE participation.

Davis Bacon and Related Acts wages apply to this project. All provisions relative to those Acts must be met.

All bidders must be registered in the System for Award Management (SAM.gov), provide their Unique Entity Id (UEI), and have an active status.

The low responsive bidder must assure compliance with the requirements of Public Law 115-232, Section 889, Prohibition on Certain Telecommunications and Video Surveillance Services or Equipment. Contractors must assure that telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities), and video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities) WILL NOT be supplied for the project.

Your special attention is invited to the attached Bidders Activity Report (BAR), Forms A and B, and Debar-2 form. The BAR form must be completed and submitted with your bid proposal, along with either Form A or Form B, and

Debar-2 form. Failure to submit the Form BAR, appropriate form A or B, and Debar-2 form will cause the bid to be rejected. Completion of the Bidders Activity Report is necessary in order to fulfill the requirements of obtaining a complete list of contractors contacted with regard to this project, in accordance with 49 CFR 26.11c. Statistical information used from the Bidders Activity Report will be used in the calculation of the next year’s DBE goals. By completing Form A, you are advising the City how the contract goal will be met. In the event you believe you will be unable to meet the goals, the attached Form B must be completed and submitted with the Bid Proposal. Please be advised that good-faith efforts will be subjected to close scrutiny and if the good-faith effort submission is unacceptable, your bid will be rejected.

A Prebid Conference will be held on Friday, October 25, 2024 at 10:00am at the Sioux Falls Law Enforcement Center – East Training Room, 320 West Fourth Avenue Sioux Falls, South Dakota.

Published twice on Oct. 18 & Oct. 25, 2024 at the approximate cost of $106.98, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18 & Oct. 25, 2024

BID REQUEST NO. 25-1004
NOTICE TO BIDDERS

The City of Sioux Falls, SD requests formal bids for: Orpheum Theatre Dressing Room Remodel.

To participate, you must be registered as a vendor in Bonfire. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” under the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through Bonfire and will be received by Bonfire not later than 2 p.m., Central time, November, 7, 2024. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at https://www.siouxfalls.gov/business-permits/bids- procurement/purchasing-bid-opening.

It is the bidder’s responsibility to check the Bonfire website for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the Bonfire website.

Telegraphic, fax, email, and hand-delivered responses will not be accepted unless specifically authorized in the terms and conditions of the Invitation to Bid.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make Award(s) as deemed to be in the best interest of Sioux Falls, SD.

There will be a pre-bid walk-through of the Project held on Monday, October 28, 2024 at 11:00 AM. Interested bidders should gather in the main lobby of the Orpheum Theatre. This is an important meeting for prospective bidders but it is not a mandatory prerequisite to submitting a bid.

Published twice on Oct. 18 & Oct. 25, 2024 at the approximate cost of $36.43, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18 & Oct. 25, 2024

BID REQUEST NO. 24-1077
NOTICE TO BIDDERS

The City of Sioux Falls, SD, requests formal bids for Basin 15 EQ Basin and Lift Station, Phase 2C Extension Project.

To participate, you must be registered as a vendor in Bonfire. Register at siouxfalls.bonfirehub.com by selecting “New Vendor Registration” under the login tab. After you have registered, navigate to the Open Public Opportunities tab to view this invitation for bid. Bids will be electronically submitted through Bonfire and will be received by Bonfire not later than 2 p.m., Central time, November 7, 2024. Bids will be publicly opened and read at 3 p.m., Central time, City Hall, 224 W. 9th St., Sioux Falls, SD 57104. You may watch the bid opening virtually via Webex by utilizing information and links located at www.siouxfalls.gov/business-permits/bids-procurement/purchasing-bid-opening.

Specifications and bid forms that must be used are available online at siouxfalls.bonfirehub.com. Cite Bid Request No. 24-1077.

It is the bidder’s responsibility to check the Bonfire website for any changes or updates to the Invitation to Bid, which will be in the form of an addendum posted to the Bonfire website.

The City of Sioux Falls reserves the right to reject any or all bids, waive technicalities, and make award(s) as deemed to be in the best interest of Sioux Falls, SD.

Federal financial assistance will be used to fund all or a portion of the contract. The contractor will comply with all applicable Federal laws, regulations, executive orders, Federal policies, procedures, and directives including, but not limited to 2 CFR §§200.318-200.327.

The City of Sioux Falls has adopted a Disadvantaged Business Enterprise Plan. This Plan expresses the commitment of the City of Sioux Falls that disadvantaged business enterprises have the maximum opportunity to compete for and perform federally assisted contracts and subcontracts.

The City of Sioux Falls has available the latest Disadvantaged Business Enterprise directory in the Engineering office to facilitate identifying those certified disadvantaged business enterprises within the state of South Dakota.

Bidders for this work will be required to comply with the President’s Executive Order Nos. 11246 as amended, 11518 and 11625 as amended. The requirements for bidders and contractors under these orders are explained in the specifications.

Bidders on this work will be required to comply with Title 40 CFR 33 and Executive Order 12138. The requirements for bidders and contractors under this regulation which concerns utilization of Disadvantaged/Minority Business Enterprises (DBE/MBE) and Women’s Business Enterprises (WBE) are explained in the specifications. The DBE/MBE and WBE goals for participation in this contract in terms of percentage of contract value are as follows: MBE 1.0 percent; WBE 4.0 percent.

Only firms certified at the time of the letting and included on the DBE Directory at dot.sd.gov, will count toward DBE participation.

Davis Bacon and Related Acts wages apply to this project. All provisions relative to those Acts must be met.

All bidders must be registered in the System for Award Management (SAM.gov), provide their Unique Entity Id (UEI), and have an active status.

To be considered a responsive bidder, the bidder must certify to compliance with the American Iron and Steel provision of the Consolidated Appropriations Act of 2014. This certification form may be found on page AIS-21 of the State Revolving Fund (SRF) General Conditions and must be included in the bid proposal.

Please be advised that waivers or exemptions from the American Iron and Steel provision that cite International Trade Agreements DO NOT comply with the Consolidated Appropriations Act of 2014 as it applies to the SRF programs. Claims from suppliers that the American Iron and Steel provision do not apply to certain products based on the International Trade Agreement exemptions of the Consolidated Appropriations Act of 2014 will not be accepted.

The low responsive bidder must assure compliance with the requirements of Public Law 115-232, Section 889, Prohibition on Certain Telecommunications and Video Surveillance Services or Equipment. Contractors must assure that telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities), and video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities) WILL NOT be supplied for the project.

Your special attention is invited to the attached Bidders Activity Report (BAR), Forms A and B, and Debar-2 form. The BAR form must be completed and submitted with your bid proposal, along with either Form A or Form B, and Debar-2 form. Failure to submit the Form BAR, appropriate form A or B, and Debar-2 form will cause the bid to be rejected. Completion of the Bidders Activity Report is necessary in order to fulfill the requirements of obtaining a complete list of contractors contacted with regard to this project, in accordance with 49 CFR 26.11c. Statistical information used from the Bidders Activity Report will be used in the calculation of the next year’s DBE goals. By completing Form A, you are advising the City how the contract goal will be met. In the event you believe you will be unable to meet the goals, the attached Form B must be completed and submitted with the Bid Proposal. Please be advised that good-faith efforts will be subjected to close scrutiny and if the good-faith effort submission is unacceptable, your bid will be rejected.

Information regarding a project sign for Bipartisan Infrastructure Law (BIL) for the State Revolving Fund Programs for BIL funded projects must be included. Information for BIL project sign requirements may be found at https://danr.sd.gov/Funding/docs/BIL%20Guidelines.pdf.

A Prebid Conference will be held on October 28, 2024 at 9:00 a.m. at the City Center, Room 110- Cooper Room, 231 N. Dakota Avenue, Sioux Falls, SD.

Published twice on Oct. 18 & Oct. 25, 2024 at the approximate cost of $126.89, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18 & Oct. 25, 2024

NOTICE OF SALE

NOTICE IS HEREBY GIVEN THAT THE CITY OF SIOUX FALLS WILL HOLD A PUBLIC AUCTION OF SURPLUS PROPERTY ONLINE STARTING OCTOBER 25, 2024.
Online auction will begin on Friday, October 25, 2024, at www.purplewave.com and will close the bidding on Tuesday, November 5, 2024 at approximately 10:00 A.M.
Auction items can be viewed at www.purplewave.com or www.siouxfalls.gov/
business-permits/bids-procurement/auction.
All non-titled equipment are subject to sales tax. Items will be available for review at www.purplewave.com on Friday, October 25, 2024. All items are sold as is, where is, and must be removed from the auction site per the City’s direction.
Additional information may be obtained by contacting the Jake Warembourg from Purple Wave at 605-660-8455, or by visiting the Purple Wave website at www.purplewave.com.
Published twice on Oct. 18 & Oct. 25, 2024 at the approximate cost of $21.63, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, 2024

NOTICE OF HEARING UPON APPLICATIONS FOR SALE OF ALCOHOLIC BEVERAGES

Notice is given that various Alcoholic Beverage Licenses are to be operated at various locations in Sioux Falls, South Dakota, as listed below.

The City Council will consider said applications at Carnegie Town Hall, 235 West Tenth Street, at 6:00 p.m., on November 6, 2024.

Any person interested may appear and be heard.

Transfer of 2024 Package Liquor License from Cubby’s Inc., 3420 North Cliff Avenue, to OneStop North Cliff LLC, 3420 North Cliff Avenue.

Transfer of 2024 Package Liquor License from Vikash Patel, 4105 West 57th Street, to Maple Inc., Get-N-Lit, 4109 West 57th Street.

Special One-Day Wine License for Sioux Falls Lutheran Booster Club to be operated at Sioux Falls Lutheran School, 6715 South Boe Lane, for a fundraiser on November 9, 2024.

Published once on Oct. 18, 2024, at the approximate cost of $12.33, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, 2024

ORDINANCE NO. 92-24

AN ORDINANCE OF THE CITY OF SIOUX FALLS, SD, AMENDING THE CODE OF ORDINANCES OF THE CITY BY AMENDING CHAPTER 160: ZONING, SUBCHAPTER: FENCES.

BE IT ORDAINED BY THE CITY OF SIOUX FALLS, SD:

Section 1. That Section 160.480 of the Code of Ordinances of Sioux Falls, SD, is hereby amended by adding Subsection (l) to read:

§ 160.480 FENCES.

   (l)   A fence post must be secured below ground level in all residential zoning districts.

Date adopted: 10/16/24 .

Paul TenHaken, Mayor

ATTEST:

Jermery J. Washington, City Clerk

Published once on Oct. 18, 2024, at the approximate cost of $9.48, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, 2024

MINUTES

City Council Meeting

Wednesday, October 16, 2024, at 6:00 PM

Carnegie Town Hall, 235 West 10th St., Sioux Falls, South Dakota 57104

CALL TO ORDER

1. MEETING ROLL CALL

Present: Council Member Richard L. Thomason, Council Member David Barranco, Council Member Miranda Basye, Council Member Sarah Cole, Council Member Rich Merkouris, Council Member Jennifer Sigette, Council Member Curt Soehl, Council Member Ryan Spellerberg

Absent: Mayor Paul TenHaken

2. INVOCATION

• Pastor Charlie Moore, Sunnycrest United Methodist Church

3. PLEDGE OF ALLEGIANCE

CONSENT AGENDA

4. APPROVAL OF THE CONSENT AGENDA

A motion was made by Council Member Merkouris and seconded by Council Member Cole to approve the Consent Agenda.

Roll call vote to approve. 8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

5. APPROVAL OF MINUTES

• Informational Meeting of Tuesday, October 8, 2024

• City Council Meeting of Tuesday, October 8, 2024

COMMUNICATIONS

6. Approval of contracts/agreements over $100K on the memorandum dated October 11, 2024.

APPLICATIONS

7. Special One-Day Malt Beverage License for T Slat Inc., to be operated at Morstad Field, 2700 South Grange Avenue, for a soccer game on October 18, 2024.

8. Special One-Day Malt Beverage Licenses for T Slat Inc., to be operated at Midco Arena, 2510 South Grange Avenue, for hockey games on October 18, 19, November 1 and 2, 2024.

9. Special One-Day Liquor Licenses for T Slat Inc., to be operated at the Elmen Center, 2505 South Grange Avenue, for volleyball games on October 19, 24 & 29, 2024.

10. Special One-Day Liquor License for T Slat, Inc., to be operated at Kirkeby-Over Stadium, 2700 South Lake Avenue, for a football game on October 19, 2024.

11. Special One-Day Malt Beverage and Special One-Day Wine Licenses for T Slat Inc., to be operated at Startup Sioux Falls, 100 East 6th Street, for a mixer on October 22, 2024.

12. Special One-Day Malt Beverage License for Estetica Unisex Mia LLC, to be operated at the Coliseum, 515 North Main Avenue, for a boxing event on October 19, 2024.

13. Special One-Day Malt Beverage and Special One-Day Wine Licenses for Interstate House of Pancakes Inc., to be operated at Underground by Rehfeld’s, 431 North Phillips Avenue, Suite 000, for a fundraiser on November 14, 2024.

14. Special One-Day Malt Beverage License for Estetica Unisex Mia LLC, to be operated at the Coliseum, 515 North Main Avenue, for comedy show on November 2, 2024.

NOTICE OF HEARINGS

15. Set a date of hearing for Wednesday, November 6, 2024. Transfer of 2024 Package Liquor License from Cubby’s Inc., 3420 North Cliff Avenue, to OneStop North Cliff LLC, 3420 North Cliff Avenue.

16. Set a date of hearing for Wednesday, November 6, 2024. Transfer of 2024 Package Liquor License from Vikash Patel, 4105 West 57th Street, to Maple Inc., Get-N-Lit, 4109 West 57th Street.

17. Set a date of hearing for Wednesday, November 6, 2024. Special One-Day Wine License for Sioux Falls Lutheran Booster Club to be operated at Sioux Falls Lutheran School, 6715 South Boe Lane, for a fundraiser on November 9, 2024.

REGULAR AGENDA

18. APPROVAL OF THE REGULAR AGENDA

A motion was made by Council Member Merkouris and seconded by Council Member Barranco to approve the Regular Agenda.

Roll call vote to approve. 8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

UNFINISHED BUSINESS

19. New 2024-25 Retail Malt Beverage License and New 2024 Retail Wine License for Swamp Daddy’s Cajun Kitchen, 421 North Phillips Avenue, Suite 115.

20. Transfer of 2024 Retail Liquor License from House of Kings Inc., 901 West Russell Street, to Casa Del Rey Inc., 901 West Russell Street.

21. Transfer of 2024 Package Liquor License from Taylor Oil Company, 3300 South Minnesota Avenue, to Highball LLC, Highball Bar, 440 East Eighth Street, Suite 101.

22. Special One-Day Wine License for Augustana University, 2121 South Summit Avenue, for a Paint & Sip Event on December 7, 2024.

A motion was made by Council Member Thomason and seconded by Council Member Basye to approve Items 19 through 22.

Roll call vote to approve. 8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

INTRODUCTION AND ADOPTION OF ORDINANCES

ORDINANCE SECOND READINGS

23. 2nd Reading: AN ORDINANCE OF THE CITY OF SIOUX FALLS, SD, AMENDING THE CODE OF ORDINANCES OF THE CITY BY AMENDING CHAPTER 160: ZONING, SUBCHAPTER: FENCES. The Planning Commission recommends approval (5-0).

Sponsors: Council Members Basye and Spellerberg

A motion was made by Council Member Basye and seconded by Council Member Spellerberg to adopt Ordinance No. 92-24.

Roll call vote to adopt. 8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

ORDINANCE FIRST READINGS

24. 1st Reading: AN ORDINANCE OF THE CITY OF SIOUX FALLS, SD, REZONING PROPERTY LOCATED AT 209 E. 34TH ST. FROM THE RS SINGLE-FAMILY RESIDENTIAL—SUBURBAN DISTRICT TO THE RT-1 SINGLE-FAMILY RESIDENTIAL—TRADITIONAL DISTRICT, NO.020156-2024, AND AMENDING THE OFFICIAL ZONING MAP OF THE CITY OF SIOUX FALLS. The Planning Commission recommends approval (4-0).

Private Applicant(s): Andrew Venrick

A motion was made by Council Member Barranco and seconded by Council Member Merkouris to set a date of 2nd Reading for Wednesday, November 6, 2024 for Item 24.

Roll call vote to set a date of 2nd Reading. 8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

HEARINGS AND RESOLUTIONS

25. A RESOLUTION ADVISING AND GIVING CONSENT TO THE APPOINTMENT OF MEMBERS TO CERTAIN CITIZEN BOARDS.

Sponsor: Mayor

A motion was made by Council Member Barranco and seconded by Council Member Basye to adopt Resolution No. 110-24.

Roll call vote to adopt. 8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

RESOLUTION NO. 110-24

A RESOLUTION ADVISING AND GIVING CONSENT TO THE APPOINTMENT OF MEMBERS TO CERTAIN CITIZEN BOARDS.

BE IT RESOLVED BY THE CITY OF SIOUX FALLS, SD:

That it gives its advice and consent to the following Mayoral appointments:

Name Board Term

Ivy Oland Dandar Arts Commission Appointed for a term from October 2024 to October 2027.

Jim Speirs Arts Commission Appointed for a term from October 2024 to October 2027.

Mike Hart Arts Commission Appointed for a term from October 2024 to October 2027.

Vaney Hariri Arts Commission Appointed for a term from October 2024 to October 2027.

Lisa Conlin Arts Commission Appointed for a term from October 2024 to October 2027.

Em Nguyen Arts Commission Appointed for a term from October 2024 to October 2027.

Jennifer Smith Hoesing Arts Commission Appointed for a term from October 2024 to October 2027.

Tyson Schultz Visual Arts Committee Appointed for a term from October 2024 to October 2027.

Kathy Dang Visual Arts Committee Appointed for a term from October 2024 to October 2027.

Scott Parsons Visual Arts Committee Appointed for a term from October 2024 to October 2027.

Alix Andal Visual Arts Committee Appointed for a term from October 2024 to October 2027.

Date adopted: 10/16/24 .

Paul TenHaken, Mayor

ATTEST:

Jermery J. Washington, City Clerk

26. A RESOLUTION DECLARING CERTAIN EQUIPMENT OF THE CITY OF SIOUX FALLS SURPLUS AND AUTHORIZING THE GIFTING TO SOUTH DAKOTA URBAN INDIAN HEALTH, INC.

Sponsor: Mayor

A motion was made by Council Member Basye and seconded by Council Member Spellerberg to adopt Resolution No. 111-24.

Roll call vote to adopt. 8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

RESOLUTION NO. 111-24

A RESOLUTION DECLARING CERTAIN EQUIPMENT OF THE CITY OF SIOUX FALLS SURPLUS AND AUTHORIZING THE GIFTING TO SOUTH DAKOTA URBAN INDIAN HEALTH, INC.

WHEREAS, the City owns a 2016 Chevrolet Traverse vehicle identified with asset no. 4001655 and VIN no. 1GNKVFED1GJ248570; and

WHEREAS, pursuant to SDCL 6-5-2, any political subdivision may convey and transfer any real or personal property which is held or owned by it, the title to which has been obtained and which is not held for public use or which is about to be abandoned for public purposes, to another political subdivision or nonprofit corporation for public, charitable, or humanitarian purposes and accommodation without offering the property for sale and without requiring the political subdivision or nonprofit corporation to pay for the property; and

WHEREAS, pursuant to SDCL 6-13-1, the governing board of a political subdivision may sell, trade, loan, destroy, or otherwise dispose of any land, structures, equipment, or other property which the governing board has, by appropriate motion, determined is no longer necessary, useful, or suitable for the purpose for which it was acquired; and

WHEREAS, the above-described personal property is no longer necessary, useful, or suitable for the purpose for which it was acquired by the City and has been declared as surplus; and

WHEREAS, South Dakota Urban Indian Health, Inc. finds it desirable to acquire said property; and

WHEREAS, South Dakota Urban Indian Health, Inc. is a South Dakota domestic nonprofit corporation;

NOW, THEREFORE, BE IT RESOLVED BY THE CITY OF SIOUX FALLS, SD:

Section 1. That the recitals above are adopted and are incorporated herein by this reference as if set out in full.

Section 2. That, pursuant to SDCL Chapter 6-13, the 2016 Chevrolet Traverse vehicle identified above is surplus property that is no longer necessary, useful, or suitable for the purpose for which it was acquired.

Section 3. That the gifting for a public purpose by the City of Sioux Falls of the 2016 Chevrolet Traverse vehicle to South Dakota Urban Indian Health, Inc. is hereby approved.

Date adopted: 10/16/24 .

Paul TenHaken, Mayor

ATTEST:

Jermery Washington, City Clerk

REPORT OF OFFICERS/BOARDS/COMMITTEES/TRANSFERS OF UNENCUMBERED APPROPRIATION BALANCES AMONG PROGRAMS WITHIN A DEPARTMENT OR ORGANIZATIONAL UNIT AS PROVIDED IN THE SIOUX FALLS CITY CHARTER SECTION 5.07(d)

27. NOTICE OF TRANSFER OF APPROPRIATIONS ON THE MEMORANDUM DATED: September 30, 2024.

NEW BUSINESS

GENERAL PUBLIC INPUT

David Zokaites spoke about abortion.

James Johnson spoke on low voter participation in elections, and elected official accountability and transparency.

Sierra Broussard spoke about right-wing activists, crime, and cooperation and finding solutions moving forward.

Riggin Scheer spoke about the historical practice of towns tarring and feathering elected officials.

ADJOURNMENT

A motion was made by Council Member Sigette and seconded by Council Member Basye to adjourn the meeting at 6:32 p.m..

Voice vote to adjourn.  8 Yes: Thomason, Barranco, Basye, Cole, Merkouris, Sigette, Soehl, Spellerberg; 0 No: (None). Motion Passed.

Jermery J. Washington, City Clerk

Published once on Oct. 18, 2024, at the approximate cost of $132.06, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

PUBLIC NOTICE

PUBLISH: Oct. 14 & Oct. 25, 2024

COURTS

PUBLISH: Oct. 11, Oct. 18 & Oct. 25, 2024

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Shannon Jay Stuefen who was sentenced in Minnehaha County on the 15 day of January, 2004,

to 2 years penitentiary suspended, $920.00 fines, costs, and restitution

for the crime of

DUI 3rd Offense

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 11, Oct. 18 & Oct. 25, 2024, at the approximate cost of $20.63, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 11, Oct. 18 & Oct. 25, 2024

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Shannon Jay Stuefen who was sentenced in Minnehaha County on the 13 day of September, 2014,

to 18 months penitentiary suspended, 2 years probation, $4104.00 fines, cost and rest.

for the crime of

Possession of Controlled Substance

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 11, Oct. 14 & Oct. 25, 2024, at the approximate cost of $20.63, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 4, Oct. 11 & Oct. 18, 2024

STATE OF SOUTH DAKOTA  COUNTY OF MINNEHAHA :SS IN CIRCUIT COURT SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
THOMAS L. HANSEN, DECEASED.
PRO. 24-265
NOTICE TO CREDITORS

Notice is hereby given that on the 27th day of September, 2024, Thomas P. Hansen, whose post office address is 312 11th Avenue, Apt. 10C, New York, New York, 10001, was appointed as Personal Representative of the Estate of Thomas L. Hansen, deceased.

Creditors of the decedent must present their claims within four months after the date of the first publication of this notice or their claims may be barred.

Claims may be delivered to or mailed to the Personal Representative or may be filed with the Clerk of the Circuit Court, and a copy of the claim mailed or delivered to the Personal Representative.

Dated this 27th day of September, 2024.

Thomas P. Hansen - Personal Representative 312 11th Avenue, Apt. 10C

New York, New York 10001

ANGELIA M. GRIES

Clerk of Circuit Court Minnehaha County Courthouse 425 N. Dakota Avenue

Sioux Falls, South Dakota 57104 (605) 367-5900

Dell Rapids Law Firm

P.O. Box 100

Dell Rapids, SD 57022-0100

(605) 428-5444

Attorneys for Personal Representative

Published on Oct. 4, Oct. 11 & Oct. 18, 2024, at the approximate cost of $49.41, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 11, Oct. 18 & Oct. 25, 2024

STATE OF SOUTH DAKOTA  COUNTY OF MINNEHAHA
:SS IN CIRCUIT COURT SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE ESTATE OF
ALAN BRYCE KAHLER, DECEASED.
PRO. 24-267
NOTICE TO CREDITORS

Notice is given that on October 3, 2024, Virginia Lee Kahler, whose address is PO Box 90516, Sioux Falls, SD  57109, was appointed as personal representative of the estate of Alan Bryce Kahler.

Creditors of decedent must file their claims within four months after the date of the first publication of this notice or their claims may be barred.

Claims may be filed with the personal representative or may be filed with the Clerk, and a copy of the claim mailed to the personal representative.

Dated this 4 day of October, 2024.
Virginia Lee Kahler

PO Box 90516

Sioux Falls, SD  57109
Clerk of Circuit Court

Minnehaha County Courthouse

425 N. Dakota Ave.

Sioux Falls, SD  57104

(605) 367-5900
Michael H. Paulson
Christopherson, Anderson,

Paulson & Fideler, LLP

426 E. 8th St.

Sioux Falls, SD  57l03-7025

(605) 336-1030

Attorneys for Personal Representative

Published on Oct. 11, Oct. 18 & Oct. 25, 2024, at the approximate cost of $48.57, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 11, Oct. 18, Oct. 25 & Nov. 1, 2024

STATE OF SOUTH DAKOTA COUNTY OF MINNEHAHA IN CIRCUIT COURT SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE PETITION OF:
HANNAH CHRISTINE LARSEN
FOR A CHANGE OF NAME TO:
HANNAH CHRISTINE ARGULA MARGETT
FILE NO: 49CIV24-4186
NOTICE OF HEARING FOR ADULT NAME CHANGE

Notice is hereby given a Verified Petition for Adult Name Change has been filed by Hannah Christine Larsen the object and prayer of which is to change Petitioner’s name from Hannah Christine Larsen to Hannah Christine Argula Margett. On the 26th day of November, 2024, at the hour of 11:00 a.m. said verified petition will be heard by this Court before the Honorable Judge Power Presiding, at the Court Room in the Minnehaha County Courthouse, City of Sioux Falls, Minnehaha County, South Dakota, or as soon thereafter as is convenient for the court. Anyone may come and appear at that time and place and show reasons, if any, why said name should not be changed as requested. Dated this 8th day of October, 2024 at Sioux Falls, South Dakota.

Sarah Patzer

Clerk of Court

Published on Oct. 11, Oct. 18, Oct. 25 & Nov. 1, 2024, at the approximate cost of $56.62, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 11, Oct. 18 & Oct. 25, 2024

STATE OF SOUTH DAKOTA COUNTY OF MINNEHAHA
IN CIRCUIT COURT SECOND JUDICIAL CIRCUIT
STATE FARM FIRE AND CASUALTY COMPANY, PLAINTIFF, VS.
MARK CRISP, INDIVIDUALLY, AND AS REGISTERED AGENT OF MARK CRISP CONSTRUCTION, LLC, A FORMER SD LIMITED LIABILITY COMPANY, DEFENDANTS.
MARK CRISP, INDIVIDUALLY, AND AS REGISTERED AGENT OF MARK CRISP CONSTRUCTION, LLC, A FORMER SD LIMITED LIABILITY COMPANY, THIRD PARTY PLAINTIFF, VS
3D PLUMBING, LLC AND JODY ELDEEN, THIRD PARTY DEFENDANTS.
NO. 49CIV24-003349
SUMMONS

THE STATE OF SOUTH DAKOTA TO THE ABOVE-NAMED THIRD PARTY DEFENDANT,

GREETINGS:

YOU ARE HEREBY SUMMONED and required to answer the third party complaint of the Third Party Plaintiff, a copy of which is herewith served upon you, and to serve a copy of your Answer on the attorney for the Third Party Plaintiff, at the address below, within thirty days from the date of the service of this Summons upon you, exclusive of the day of such service.

IF YOU FAIL TO DO SO, judgment by default may be rendered against you as requested in Third Party Plaintiff’s Complaint sixty days after the completed service of Third Party Plaintiff’s Summons and Complaint.

Dated this the 8th day of August, 2024.

Respectfully submitted,

Ryland Deinert

KLASS LAW FIRM, L.L.P. Mayfair Center, Upper Level 4280 Sergeant Road, Suite 290 Sioux City, IA 51106

clausen@klasslaw.com

deinert@klasslaw.com WWW.KLASSLAW.COM 712/252-1866 712/252-5822 fax

ATTORNEYS FOR THIRD PARTY PLAINTIFF

Published on Oct. 11, Oct. 18 & Oct. 25, 2024 at the approximate cost of $65.85, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 11, Oct. 18 & Oct. 25, 2024

STATE OF SOUTH DAKOTA COUNTY OF MINNEHAHA IN CIRCUIT COURT SECOND JUDICIAL CIRCUIT STATE FARM FIRE AND CASUALTY COMPANY, PLAINTIFF, VS.
MARK CRISP, INDIVIDUALLY, AND AS REGISTERED AGENT OF MARK CRISP CONSTRUCTION, LLC, A FORMER SD LIMITED LIABILITY COMPANY, DEFENDANTS.
NO. 49CIV24-003349
DEFENDANTS’ ANSWER, THIRD PARTY COMPLAINT, AND JURY DEMAND

COME NOW Defendants and for their answer to Plaintiff’s Complaint state:

1. Paragraph 1 is denied for lack of sufficient information.

2. Paragraph 2 is admitted.

3. Paragraph 3 is admitted that the residence located at 1402 Bitterroot Road,

Dell Rapids, South Dakota, was a spec home built in 2017 by the Defendant. The remainder of the denied for lack of sufficient information.

4. Paragraph 4 is denied.

5. Paragraph 5 is admitted that Defendant was the general contractor. The

remainder of the paragraph is denied.

6. Paragraph 6 is denied.

WHEREFORE Defendants pray that Plaintiff’s Complaint be dismissed and all costs taxed to Plaintiff.

AFFIRMATIVE DEFENSES

1. That plaintiff’s damages, if any, were caused by third parties over whom these Defendants had no control and for whom these Defendants cannot be held liable.

DEMAND FOR JURY TRIAL

Defendants hereby respectfully demand a trial by jury of all issues in this case.

THIRD PARTY COMPLAINT

1. Third Party Plaintiff is a resident of Minnehaha County, Iowa and served as the Registered Agent of Mark Crisp Construction, LLC.

2. Third Party Defendants 3D Plumbing and Jody Eldeen are residents of Minnehaha County South Dakota, and Jody Eldeen served as the Registered Agent and owner of 3D Plumbing, LLC.

3. Third Party Plaintiff hired Third Party Defendants to install plumbing in a residence later sold to Nicholas Kahler.

4. State Farm Fire and Casualty Company has sued Mark Crisp, Individually, and as Registered Agent of Mark Crisp Construction, LLC for losses related to the damages to its insured, Nicholas Kahler’s residence.

3. The alleged damages of State Farm Fire and Casualty Company, if actual, were not the fault of Third Party Plaintiffs, but were proximately caused by the negligence of 3D Plumbing, LLC and Jody Eldeen.

4. The negligence of 3D Plumbing, LLC and Jody Eldeen, included but was not necessarily limited to the following:

a. failure to properly stall the supply hose to the faucet in the upstairs bathroom.

b. failure to properly install the supply hose in a workmanlike manner consistent with good plumbing practices.

5. If the jury awards any damages to State Farm Fire and Casualty Company, 3D Plumbing, LLC and Jody Eldeen are liable for all or part of those damages.

6. The negligence of Mark Crisp, Individually, and as Registered Agent of Mark Crisp Construction, LLC, which is denied, should be imputed to 3DPlumbing, LLC and Jody Eldeen.

Respectfully submitted,

Ryland Deinert

KLASS LAW FIRM, L.L.P. Mayfair Center, Upper Level 4280 Sergeant Road, Suite 290 Sioux City, IA 51106 deinert@klasslaw.com WWW.KLASSLAW.COM 712-252-1866

712-252-5822 fax

ATTORNEYS FOR DEFENDANTS

Published on Oct. 11, Oct. 18  & Oct. 25, 2024, at the approximate cost of $111.86, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1, 2024.

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Joseph Darst who was sentenced in Minnehaha County on the 4th day of September, 1979,

to 6 months in Minn. Co. Jail

for the crime of

Grand Theft

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $19.81, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1, 2024.

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Joseph Darst who was sentenced in Minnehaha County on the 27th day of November, 1991,

to 15 years in the SDSP with 10 years suspended consecutive with count 3 for the crime of

Grand Theft - Count 1

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $21.44, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1, 2024.

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Joseph Darst who was sentenced in Minnehaha County on the 27th day of November, 1991,

to 15 years in the SDSP with 10 years suspended consecutive with count 1 for the crime of

Grand Theft - Count 3

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $21.44, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1, 2024.

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Joseph Darst who was sentenced in Minnehaha County on the 10th day of June, 1981,

to 10 months in the SDSP for the crime of

Grand Theft

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $19.00, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1, 2024.

STATE OF SOUTH DAKOTA  COUNTY OF MINNEHAHA :SS IN CIRCUIT COURT SECOND JUDICIAL CIRCUITPRO. 24-250
IN THE MATTER OF THE ESTATE OF
DANNY L. JORGENSEN,
A/K/A DANNY LYNN
JORGENSEN, DECEASED.
NOTICE TO CREDITORS

Notice is given that on October 4, 2024, Susan A. Jorgensen, whose address is 25667 473rd Avenue, Renner, SD  57055, was appointed personal representative of the estate of Danny L. Jorgensen, a/k/a Danny Lynn Jorgensen.

Creditors of decedent must file their claims within four months after the date of the first publication of this notice or their claims may be barred.

Claims may be filed with the personal representative or may be filed with the Clerk, and a copy of the claim mailed to the personal representative.

Dated this 7th day of October, 2024.

/s/ Susan A. Jorgensen Susan A. Jorgensen

25667 473rd Avenue

Renner, SD  57055

Clerk of Circuit Court

Minnehaha County Courthouse

425 N. Dakota Ave.

Sioux Falls, SD  57104

Michael H. Paulson

Christopherson, Anderson, Paulson & Fideler, LLP

426 E. 8th St.

Sioux Falls, SD  57l03-7025

(605) 336-1030

Attorneys for Personal Representative

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $48.57, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1, 2024.

STATE OF SOUTH DAKOTA  COUNTY OF MINNEHAHA :SS IN CIRCUIT COURT SECOND JUDICIAL CIRCUIT IN THE MATTER OF THE ESTATE OF
BRIAN I. FARMEN, DECEASED.
49PRO24-000272
NOTICE TO CREDITORS OF APPOINTMENT OF PERSONAL REPRESENTATIVE

Notice is given that on October 9, 2024, Dawn Michels, whose address is 2408 16th Avenue South, Fargo, North Dakota 58103, was appointed personal representative of the estate of Brian I. Farmen.

Creditors of decedent must file their claims within (4) four months after the date of the first publication of this notice or their claims may be barred.

Claims may be filed with the personal representative or may be filed with the clerk, and a copy of the claim mailed to the personal representative.

/s/Dawn Michels

Dawn Michels

2408 16th Avenue South

Fargo, ND 58103

701-541-4330

Clerk of Circuit Court

Minnehaha County Courthouse

425 N. Dakota Ave.

Sioux Falls, SD  57104

Lucas J. Carr

Woods, Fuller, Shultz & Smith P.C.

300 South Phillips Avenue, Suite 300

P.O. Box 5027

Sioux Falls, SD 57117-5027

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $48.57, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1, 2024.

STATE OF SOUTH DAKOTA COUNTY OF MINNEHAHA IN CIRCUIT COURT SECOND JUDICIAL CIRCUIT
IN THE MATTER OF THE PETITION OF:
KHALID HAGELMAHI
FOR A CHANGE OF NAME TO: KHALID MOHAMEDELMAKKI ABDALDAIM HAGELMAHI
FILE NO: 49CIV24-4168
NOTICE OF HEARING FOR ADULT NAME CHANGE

Notice is hereby given a Verified Petition for Adult Name Change has been filed by Khalid Hagelmahi the object and prayer of which is to change Petitioner’s name from Khalid Hagelmahi to Khalid MohamedElmakki Abdaldaim Hagelmahi. On the 19th day of November, 2024, at the hour of 11:00 a.m. said verified petition will be heard by this Court before the Honorable Judge John Pekas Presiding, at the Court Room in the Minnehaha County Courthouse, City of Sioux Falls, Minnehaha County, South Dakota, or as soon thereafter as is convenient for the court. Anyone may come and appear at that time and place and show reasons, if any, why said name should not be changed as requested. Dated this 7 day of October, 2024 at Sioux Falls, South Dakota.

Clerk of Court

Published on Oct. 18, Oct. 25 & Nov. 1 & Nov. 8, 2024, at the approximate cost of $55.56, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25 & Nov. 1, 2024

NOTICE TO CREDITORS

Notice is given that on September 24, 2024, First Dakota National Bank, whose address is 101 North Main Avenue, Wealth & Trust Suite #213, Sioux Falls, South Dakota 57104, was appointed Trustee of the Lorraine Gage Living Trust. Lorraine Gage passed away on August 28, 2024.

Creditors of Lorraine Gage and the Lorraine Gage Living Trust must submit their claims by December 20, 2024, or within 60 days from the first date of publication of this notice.

Claims may be mailed to the Trustee, First Dakota National Bank, 101 North Main Avenue, Wealth & Trust Suite #213, Sioux Falls, South Dakota 57104.

FIRST DAKOTA NATIONAL BANK

By: Dianne K. Harris

SVP Wealth & Trust Officer 101 North Main Avenue Wealth & Trust Suite #213 Sioux Falls, SD 57104

Lisa J. Maguire

Woods, Fuller, Shultz & Smith P.C. 300 South Phillips Avenue, Suite 300 P.O. Box 5027

Sioux Falls, SD 57117-5027 (605)336-3890

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $39.54, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com

-

PUBLISH: Oct. 18, Oct. 25, Nov. 1 & Nov. 8, 2024

STATE OF SOUTH DAKOTA COUNTY OF MINNEHAHA
IN CIRCUIT COURT JUDICIAL CIRCUIT
IN THE MATTER OF THE PETITION OF:
PAUL JOSEPH SWIFT EAGLE
FOR A CHANGE OF NAME TO: PAUL JOSEPH REYES
FILE NO: 49CIV24-4290
NOTICE OF HEARING FOR ADULT NAME CHANGE

Notice is hereby given a Verified Petition for Adult Name Change has been filed by Paul Joseph Reyes the object and prayer of which is to change Petitioner’s name from Paul Joseph Swift Eagle to Paul Joseph Reyes. On the 19 day of November, 2024, at the hour of 11:00 a.m. said verified petition will be heard by this Court before the Honorable Judge Pekas Presiding, at the Court Room in the Minnehaha County Courthouse, City of Sioux Falls, Minnehaha County, South Dakota, or as soon thereafter as is convenient for the court. Anyone may come and appear at that time and place and show reasons, if any, why said name should not be changed as requested. Dated this 11 day of October, 2024 at Minnehaha, South Dakota.

/s/Hannah Ludlow
Clerk of Court
ATTEST: ANGELIA M. GRIES
Clerk of Court
By: /s/Hannah Ludlow
Deputy
Published on Oct. 18, Oct. 25,  Nov. 1 & Nov. 8, 2024, at the approximate cost of $58.75, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25 & Nov. 1, 2024

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Peter D Thompson who was sentenced in Minnehaha County on the 2nd day of August, 2018,

to Penitentiary 10 years, 5 suspended for the crime of

Burglary - 1st Degree

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $19.80, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25 & Nov. 1, 2024

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Peter D Thompson who was sentenced in Minnehaha County on the 2nd day of August, 2018,

to Penitentiary 10 years, 5 suspended Resitution $5,136.45 for the crime of

Aggravated Assault Against Law Enforcement Officer

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $21.44, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25 & Nov. 1, 2024

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Peter D Thompson who was sentenced in Minnehaha County on the 2nd day of August, 2018,

to 2 years, 2 years suspended, $229 court costs for the crime of

DUI - 3rd

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $20.63, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

-

PUBLISH: Oct. 18, Oct. 25 & Nov. 1, 2024

NOTICE OF APPLICATION FOR EXECUTIVE CLEMENCY

Peter D Thompson who was sentenced in Minnehaha County on the 2nd day of August, 2018,

to 30 Days, 30 Days suspended, Fine $114, Costs $66 for the crime of

Disorderly Conduct

has applied to the South Dakota Board of Pardons and Paroles for: Pardon

Published on Oct. 18 & Oct. 25 and Nov. 1, 2024, at the approximate cost of $20.63, and may be viewed free of charge at www.sdpublicnotices.com or TheDakotaScout.com.

The Dakota Scout is the official newspaper of the city of Sioux Falls, the Sioux Falls School District and the city of Baltic.